Construction Damage Sample Clauses

Construction Damage. Any damage to streets and curbs, drainage inlets, sidewalks, street lights, street markers, mailboxes, walls, etc., may, at the Developer’s election, be repaired by the Developer and billed to the Homeowner by which the contractor was hired.
Sample 1Sample 2
AutoNDA by SimpleDocs
Construction Damage. In the event any activities undertaken in connection with the development, construction, commissioning or testing of Unit 2 cause any physical damage (“Construction Damage”) to Xxxx 0, to the Common Facilities or to any portion of PacifiCorp’s Area:
Sample 1
Construction Damage. Specialty shall repair any damage to the roads under the control of the Road Association caused by construction on Parcels B and C. 44. Treatment of Class 2-F – Allowed Secured Claim of VOA: Section VI.B.6 setting forth the treatment of the Allowed Secured Claim of the VOA is revised and amended to compensate the VOA as follows in full satisfaction of its Claim against the Debtors: 5 See Note 4 above. Benefit / Item Value Cash Payment to VOA for Reserves and or Deferred Villa Maintenance $ 250,000 2013 VOA dues to be paid by Villa Renaissance on Plan Effective Date (Jan 2013 - June 2013) $ 313,881 $5,000 Payment from each Villa Renaissance villa sale (as sold)* $ 350,000 Payment from 7C Clubhouse Lenders from interest payments (From Interest payments received @ $5,000 per villa)** $ 350,000 Payment of past due property taxes from Developer Villa Units $ 176,000 Sub Total - Cash Benefits $ 1,439,881 Other Benefits Accounts Payable Relief (Swirl) $ 225,000 $ Sub Total - Other Benefits to VOA $ 225,000 VOA Operations allowed to remain on site at Seven Canyons for lease of $1858.88 per mo. Total Value to VOA from the Plan of Reorganization $ 1,664,881 * This shall be an obligation of Villa Renaissance only. It will not be a debt owed by Seven Canyons Recap, LLC (“Recap”) or 7C Clubhouse Lenders (“7C”) and will not be secured by a lien on the villas. In the event of a default by Villa Renaissance on the debt owed to Recap and a subsequent foreclosure by Recap, the VOA will have no recourse against Recap, 7C or any of their assets. ** This is an obligation of 7C only. It is not a debt owed by Recap. The VOA shall be paid $5,000.00 from the proceeds from the sale of each Villa Unit that would otherwise be paid to 7C. In the event of any foreclosure by Recap, 7C agrees that the $350,000.00 shall still be owed to VOA upon 7C's receipt of the first $350,000.00 of funds by 7C.
Sample 1
Construction Damage. DC PAINTING LLC will use reasonable diligence and care to minimize coincidental damage to exterior or interior walls, wall covering, paint, glass surfaces, doors, floors or the like, which might result from work done under this contract. Delays: DC Painting LLC shall be excused from any delay in completion caused by acts of God, of Owner or Owner’s agent, Owner’s employees or Owner’s independent contractors, fire, earthquake, bad weather, labor trouble, acts or public utilities, public bodies, or inspectors(but not related to possible defects in DC painting LLC performance), extra work, failure of Owner to make progress payments promptly, or any other contingencies beyond DC Painting LLC control. The price quoted in this contract is based on performing the work during dry weather and uninterrupted by delays. Arbitration: Any substantive controversy or claim arising out of or relating to this contract or the breach thereof or any work performed in connection therewith shall be settled in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association, except as provided herein, and judgment upon the award may be entered in any court having jurisdiction thereof. Both parties to this contract, by entering into it, are conditionally waiving their legal right to have such dispute decided in a court of law, weather by judge or by jury, and instead are accepting and agreeing to the use of binding arbitration, pursuant to this paragraph, in order to effect swifter and less expensive resolution of disputes. Mere non-payment of a progress or final payment without written notification to DC Painting LLC by owner concerning the controversy shall not, however, require DC Painting LLC to seek arbitration before utilizing judicial remedies(including foreclosure of mechanics’ lien) to collect payments due. In the event that a payment is past due under the contract at the time a controversy arises, then owner or DC Painting LLC, as the case may be, shall be required to deposit the disputed payment into a finance charge bearing irrevocable trust account in a federally insured savings institution, for disbursement by the trustee in accordance with the decision of the arbitrator(s) as a condition precedent to the right to demand arbitration hereunder. Arbitration shall not, under any set of circumstances, be required of a party to whom no adequate security (by way of deposit, mechanics’ lien or other acceptable method)is available upon succ...
Sample 1
Construction Damage. Notwithstanding anything in Paragraph 3 above to the contrary, Sacramento LLC, its successors in interest and assigns, shall be solely responsible for the repair of any damage to the existing Sacramento Avenue, including without limitation the Maintenance Areas, caused by construction activities on the Sacramento LLC Property.
Sample 1
Construction Damage 
Sample 1

Related to Construction Damage

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Partial Damage or Destruction If, during the Term, any Property shall be totally or partially destroyed but the Facility is not rendered Unsuitable for Its Permitted Use, Tenant shall, subject to Section 10.2.3, promptly restore such Facility as provided in Section 10.2.4.

  • Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Upon the occurrence of any damage to the Premises, upon notice (the “Landlord Repair Notice”) to Tenant from Landlord, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.3 of this Lease, and Landlord shall repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition; provided that if the cost of such repair by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as assigned by Tenant, the cost of such repairs shall be paid by Tenant to Landlord prior to Landlord’s commencement of repair of the damage. In the event that Landlord does not deliver the Landlord Repair Notice within sixty (60) days following the date the casualty becomes known to Landlord, Tenant shall, at its sole cost and expense, repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition. Whether or not Landlord delivers a Landlord Repair Notice, prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant’s occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises. In the event that Landlord shall not deliver the Landlord Repair Notice, Tenant’s right to rent abatement pursuant to the preceding sentence shall terminate as of the date which is reasonably determined by Landlord to be the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.

  • Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.

  • Construction, Etc Each covenant contained herein shall be construed (absent express provision to the contrary) as being independent of each other covenant contained herein, so that compliance with any one covenant shall not (absent such an express contrary provision) be deemed to excuse compliance with any other covenant. Where any provision herein refers to action to be taken by any Person, or which such Person is prohibited from taking, such provision shall be applicable whether such action is taken directly or indirectly by such Person. For the avoidance of doubt, all Schedules and Exhibits attached to this Agreement shall be deemed to be a part hereof.

  • Landlord’s Damages In the event of any condemnation or taking, whether whole or partial, the Tenant shall not be entitled to any part of the award paid for such condemnation and Landlord is to receive the full amount of such award, the Tenant hereby expressly waiving any rights or claim to any part thereof.

  • PREMISES PARTIAL DAMAGE - INSURED LOSS If Premises Partial Damage that is an Insured Loss occurs, then Lessor shall, at Lessor's expense, repair such damage (but not Lessee's Trade Fixtures or Lessee-Owned Alterations and Utility Installations) as soon as reasonably possible and this Lease shall continue in full force and effect. In the event, however, that there is a shortage of insurance proceeds and such shortage is due to the fact that, by reason of the unique nature of the improvements in the Premises, full replacement cost insurance coverage was not commercially reasonable and available, Lessor shall have no obligation to pay for the shortage in insurance proceeds or to fully restore the unique aspects of the Premises unless Lessee provides Lessor with the funds to cover same, or adequate assurance thereof, within ten (10) days following receipt of written notice of such shortage and request therefor. If Lessor receives said funds or adequate assurance thereof within said ten (10) day period, Lessor shall complete them as soon as reasonably possible and this Lease shall remain in full force and effect. If Lessor does not receive such funds or assurance within said period, Lessor may nevertheless elect by written notice to Lessee within ten (10) days thereafter to make such restoration and repair as is commercially reasonable with Lessor paying any shortage in proceeds, in which case this Lease shall remain in full force and effect. If Lessor does not receive such funds or assurance within such ten (10) day period, and if Lessor does not so elect to restore and repair, then this Lease shall terminate sixty (60) days following the occurrence of the damage or destruction. Unless otherwise agreed, Lessee shall in no event have any right to reimbursement from Lessor for any funds contributed by Lessee to repair any such damage or destruction. Premises Partial Damage due to flood or earthquake shall be subject to Paragraph 9.3 rather than Paragraph 9.2, notwithstanding that there may be some insurance coverage, but the net proceeds of any such insurance shall be made available for the repairs if made by either Party.

  • Damage or Destruction of Premises (a) If the Premises or any part thereof shall be damaged by fire or other insured casualty, then, subject to the last paragraph of this Section, Landlord shall proceed with diligence, subject to then applicable statutes, building codes, zoning ordinances and regulations of any governmental authority, and at the expense of Landlord (but only to the extent of insurance proceeds made available to Landlord by any mortgagee of the Building and any ground lessor) to repair or cause to be repaired such damage (other than any Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and Tenant Work, which Tenant shall promptly commence, and proceed with diligence, to restore). All such repairs made necessary by any act or omission of Tenant shall be made at the Tenant’s expense to the extent that the cost of such repairs are less than the deductible amount in Landlord’s insurance policy. All repairs to and replacements of Tenant Property not deemed to be fixtures covered by Landlord’s property insurance and any Initial Tenant Improvements and Tenant Work shall be made by and at the expense of Tenant. The cost of any repairs performed under this Section by Landlord at Tenant’s request and at Tenant’s expense (including costs of design fees, financing, and charges for administration, overhead and construction management services by Landlord and Landlord’s contractor) shall constitute Additional Rent hereunder. If the Premises or any part thereof shall have been rendered unfit for use and occupation hereunder by reason of such damage, the Base Rent or a just and proportionate part thereof, according to the nature and extent to which the Premises shall have been so rendered unfit, shall be abated until the Premises (except as to Tenant Property, Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and any Tenant Work) shall have been restored as nearly as practicable to the condition in which they were immediately prior to such fire or other casualty; and that if and to the extent Landlord shall be unable to collect the insurance proceeds (including rent insurance proceeds) applicable to such damage because of some action or inaction on the part of Tenant, or the employees, licensees or invitees of Tenant, the cost of repairing such damage shall be paid by Tenant and there shall be no abatement of rent. Landlord shall not be liable for delays in the making of any such repairs that are due to government regulation, casualties, and strikes, unavailability of labor and materials, delays in obtaining insurance proceeds, and other causes beyond the reasonable control of Landlord, nor shall Landlord be liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting from delays in repairing such damage. If the Premises or the Building are substantially damaged so as to prevent Tenant from using the Premises for the Permitted Use and the Premises have not been restored to the condition required pursuant to the terms of this Lease within two hundred and seventy (270) days following said casualty (or if such casualty occurs during the last 18 months of the term, within ninety (90) days after the date of such casualty), then Tenant may terminate this Lease upon thirty (30) days written notice to Landlord unless Landlord shall substantially complete such repair and restoration within such thirty (30) day period in which event Tenant’s termination shall be void and of no further force or effect.

  • Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.

  • Construction Warranty At the Closing, Seller shall assign to Buyer all construction warranties with respect to the Hotel, which assignment shall be in form and substance reasonably satisfactory to Buyer, including a warranty by the Contractor, for the period ending not sooner than one (1) year after the date the Hotel is Substantially Completed, in the form of the warranty attached hereto as Exhibit H (the “Construction Warranty”).

Time is Money Join Law Insider Premium to draft better contracts faster.