Construction and Misc Sample Clauses

Construction and Misc. This Agreement shall be governed exclusively by the laws of the State of Florida without reference to conflict of laws and the exclusive venue for any action, claim or dispute in respect of this Agreement shall be such court of competent jurisdiction as is located in Broward County Florida as the sole venue. The parties agree and acknowledge that each has reviewed this Agreement and the normal rule of construction that agreements are to be construed against the drafting party shall not apply in respect of this Agreement given the parties have mutually negotiated and drafted this Agreement. The COMPANY irrevocably submits to the exclusive jurisdiction stated herein and the parties hereto agree that a final judgment in any such action or proceeding shall be conclusive and may be enforced in other jurisdictions by suit on the judgment or in any other manner provided by law. The parties hereto further waive any objection to venue in the said place. THE DEBTOR IRREVOCABLY WAIVES THE DEFENSE OF AN INCONVENIENT FORUM TO THE MAINTENANCE OF SUCH SUIT OR PROCEEDING AND FURTHER AGREES THAT SERVICE OF PROCESS UPON THE PARTY MAILED BY FIRST CLASS MAIL SHALL BE DEEMED IN EVERY RESPECT EFFECTIVE SERVICE OF PROCESS UPON THE PARTY IN ANY SUCH SUIT OR PROCEEDING. NOTHING HEREIN SHALL AFFECT EITHER PARTY’S RIGHT TO SERVE PROCESS IN ANY OTHER MANNER PERMITTED BY LAW. The COMPANY waives personal service of any summons, complaint or other process in connection with any such action or proceeding and agrees that service thereof may be made, as the CLAIMANT may elect, by mail directed to the CLAIMANT at the last known principal business location or mailing address or, in the alternative, in any other form or manner permitted by law, on a non-exclusive basis, as determined by the CLAIMANT. No failure or delay on the part of the CLAIMANT in the exercise of any power, right or privilege hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any such power, right or privilege preclude other or further exercise thereof or of any other right, power or privileges. The obligations to CLAIMANT and this Agreement cannot be set off against any real or alleged claim against the CLAIMANT.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Construction and Misc. This Agreement shall be governed exclusively by the laws of the State of New York without reference to conflict of laws and the exclusive venue for any action, claim or dispute in respect of this Agreement shall be such court of competent jurisdiction as is located in Nassau County New York as the sole venue. The parties agree and acknowledge that each has reviewed this Agreement and the normal rule of construction that agreements are to be construed against the drafting party shall not apply in respect of this Agreement given the parties have mutually negotiated and drafted this Agreement.
Sample 1Sample 2
Construction and Misc. This Agreement shall be governed exclusively by the laws of the State of New York without reference to conflict of laws and the exclusive venue for any action, claim or dispute in respect of this Agreement shall be such court of competent jurisdiction as is located in New York County New York as the sole venue. The parties agree and acknowledge that each has reviewed this Agreement and the normal rule of construction that agreements are to be construed against the drafting party shall not apply in respect of this Agreement given the parties have mutually negotiated and drafted this Agreement. The Company irrevocably submits to the exclusive jurisdiction stated herein and the parties hereto agree that a final judgment in any such action or proceeding shall be conclusive and may be enforced in other jurisdictions by suit on the judgment or in any other manner provided by law. The parties hereto further waive any objection to venue in the said place. Effective Date: February 3, 2012 Principal Amount due hereunder: $1,700,000. Purchase Price: $1,500,000 Interest due hereunder: 0% per annum Maturity Date: Date that is 18 months from this Effective Date Description of Debt: Purchase of debt Assignor :LV Administrative Services, Ltd. Name of Company: Pervasip Corp State of Incorporation of Company: New York Address of Company: 00 Xxxxx Xxxxxxxx #000,Xxxxx Xxxxxx, XX 00000 Name of Claimant: JDM Group, LLC The undersigned hereby execute this document, which shall be deemed effective on the Effective Date noted: "Company/Debtor" Pervasip Corp. By: Xxxx X. Xxxx Its: Chief Executive Officer “Claimant” JDM Group, LLC By: /s/ Xxxxxx MacLlellan
Sample 1

Related to Construction and Misc

  • Construction, Etc Each covenant contained herein shall be construed (absent express provision to the contrary) as being independent of each other covenant contained herein, so that compliance with any one covenant shall not (absent such an express contrary provision) be deemed to excuse compliance with any other covenant. Where any provision herein refers to action to be taken by any Person, or which such Person is prohibited from taking, such provision shall be applicable whether such action is taken directly or indirectly by such Person. For the avoidance of doubt, all Schedules and Exhibits attached to this Agreement shall be deemed to be a part hereof.

  • Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Construction of the Project The Corporation hereby represents that it has caused the Project to be completed and acknowledges that it shall not be entitled to any reimbursement for the cost of construction of the Project from the Authority, the Trustee or the Holders of the Bonds, nor shall it be entitled to any diminution or postponement of the payments required to be paid by the Corporation pursuant to this Participation Agreement or the Corporation Obligations. Section 3.04.

  • Operation and Maintenance Throughout the period prior to any Termination of NAI’s Work, NAI must operate and maintain the Property in a good and workmanlike manner and in compliance with Applicable Laws in all material respects and pay or cause to be paid all fees or charges of any kind in connection therewith. (If NAI does not promptly correct any failure of the Property to comply with Applicable Laws that is the subject of a written complaint or demand for corrective action given by any Governmental Authority to NAI, or to BNPPLC and forwarded by it to NAI, then for purposes of the preceding sentence, NAI will be considered not to have maintained the Property “in compliance with all Applicable Laws in all material respects” whether or not the noncompliance would be material in the absence of the complaint or demand.) NAI must not use or occupy, or allow the use or occupancy of, the Property in any manner which violates any Applicable Law or which constitutes a public or private nuisance or which makes void, voidable or cancelable any insurance then in force with respect thereto. Without limiting the generality of the foregoing, NAI must not conduct or permit others to conduct Hazardous Substance Activities on the Property, except Permitted Hazardous Substance Use and Remedial Work; and NAI must not discharge or permit the discharge of anything (including Permitted Hazardous Substances) on or from the Property that would require any permit under applicable Environmental Laws, other than (1) storm water runoff, (2) fume hood emissions, (3) waste water discharges through a publicly owned treatment works, (4) discharges that are a necessary part of any Remedial Work, and (5) other similar discharges consistent with the definition of Permitted Hazardous Substance Use which do not significantly increase the risk of Environmental Losses to BNPPLC, in each case in strict compliance with Environmental Laws. To the extent that any of the following would, individually or in the aggregate, increase the likelihood of a 97-10/Meltdown Event or materially and adversely affect the value of the Property or the use of the Property for purposes permitted by this Agreement, NAI must not, without BNPPLC’s prior consent: (i) initiate or permit any zoning reclassification of the Property; (ii) seek any variance under existing zoning ordinances applicable to the Property; (iii) use or permit the use of the Property in a manner that would result in such use becoming a nonconforming use under applicable zoning ordinances or similar laws, rules or regulations; (iv) execute or file any subdivision plat affecting the Property; or (v) consent to the annexation of the Property to any municipality. NAI will not cause or permit any drilling or exploration for, or extraction, removal or production of, minerals from the surface or subsurface of the Property, and NAI must not do anything that could reasonably be expected to significantly reduce the market value of the Property. If NAI receives a notice or claim from any federal, state or other governmental authority that the Property is not in compliance with any Applicable Law, or that any action may be taken against BNPPLC because the Property does not comply with any Applicable Law, NAI must promptly furnish a copy of such notice or claim to BNPPLC.

  • Construction of Project Purchaser shall (i) perform the Final Assembly Work which is set forth in Exhibit P hereto, (ii) perform all civil works (including roads, grading, maintenance facilities, meteorological towers and other items); (iii) perform all electrical works (including collection lines, Electrical Infrastructure, Transmission Facilities, Interconnection Facilities and other items); (iv) provide and install a remote terminal unit and cabling to the Substation, meteorological towers, and communications lines for the SCADA System to the Substation; and (v) provide any other items required for the operation of the Project; and

  • Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.

  • Construction of Improvements (A) Lessee warrants and agrees that the Building will be constructed on the Leased Premises, and all other improvements to the land, including the parking lot, approaches, and service areas, will be constructed in all material respects by Lessee substantially in accordance with the plot, plans, and specifications heretofore submitted to Lessor.

  • OPERATION AND MAINTENANCE OF COMMON AREAS During the Term, Landlord shall operate all Common Areas within the Building and the Project. The term “Common Areas” shall mean all areas within the Building, Project and other buildings in the Project which are not held for exclusive use by persons entitled to occupy space.

  • Specific Shall Not Limit General; Construction No specific provision contained in this Note shall limit or modify any more general provision contained herein. This Note shall be deemed to be jointly drafted by the Company and the Holder and shall not be construed against any person as the drafter hereof.

Time is Money Join Law Insider Premium to draft better contracts faster.