Consequences of Delays Sample Clauses

Consequences of Delays. (a) If Seller does not reasonably expect to achieve the Commercial Operation Date Milestone by October 1, 2010 in accordance with Section 3.1, Seller shall provide prompt written notice (a “Commercial Operation Delay Notice”) to Purchaser of such expectation, the expected period of delay and the cause of the delay. Seller’s estimate of the expected period of delay shall be based on the best information available to Seller, and Seller shall promptly notify Purchaser of any expected changes in such period. Notwithstanding any such Commercial Operation Delay Notice or any failure of the Commercial Operation Date to occur on or before February 1, 2011, the Delivery Start Date shall nevertheless be the date specified in Section 3.1(a). With respect to nominations of Gas during the Commercial Operation Delay Period, Purchaser may make nominations for Scheduled Gas in an amount up to the Baseload Quantity on any Day during the Commercial Operation Delay Period, notwithstanding the fact that the quantity of Gas available from the Facility on such Day specified in the applicable Monthly Availability Plan or Daily Availability Schedule may be none, but otherwise in accordance with Article VI. If Purchaser makes such nominations for Scheduled Gas during the Commercial Operation Delay Period, Seller shall compensate Purchaser for all Replacement Gas Costs for the Scheduled Gas, except to the extent Seller delivers Replacement Gas therefor at the Delivery Point.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Consequences of Delays. (a) Without limiting clause 19.1 of this Agreement, Superior Jetties will not be liable if provision of the Works is prevented or delayed due to any act, omission or default of the Customer or any party under or through the Customer (including but not limited to a failure to provide access to the Site or to pay the Price pursuant to the terms of this Agreement).‌
Sample 1Sample 2
Consequences of Delays. If Landlord does not Substantially Complete Landlord’s Work, the Tenant Improvements and/or the Landlord Project Improvements by December 15, 2008 for any reason other than the occurrence of an Event of Force Majeure or Tenant’s Delay, then Tenant may deduct from installments of Base Rent and Additional Rent subsequently becoming due under the terms, of this Agreement the amount of $3,956.00 per day for each day that said failure continues, which amount is acknowledged to be fair and reasonable liquidated damages, and not a penalty, and which remedy shall be Tenant’s sole remedy for said delay, except as explicitly set forth in this Lease. If Landlord’s Work, the Tenant Improvements and/or the Landlord Project Improvements have not been Substantially Completed by April 1, 2009 (i) for any reason other than the occurrence of an Event of Force Majeure or Tenant’s Delay, then, in addition to any and all other available rights and remedies (excluding any claim for consequential, exemplary or lost profit damages), Tenant shall have the right to terminate this Lease, or (ii) for any reason other than Tenant’s Delay, then, if Tenant does not elect to terminate this Lease pursuant to clause (i), above, then Tenant may deduct from installments of Base Rent and Additional Rent subsequently becoming due under the terms of this Agreement the amount of Seven Thousand Five Hundred Dollars ($7,500.00) per day for each day that said failure continues, which amount is acknowledged to be fair and reasonable liquidated damages, and not a penalty, and which remedy shall be Tenant’s sole remedy for said delay, except as explicitly set forth in this Lease.
Sample 1
Consequences of Delays. (a) This section has been intentionally deleted.
Sample 1
Consequences of Delays. (a) In the event of a failure by Seller to achieve any Milestone with respect to a Dedicated Unit on or before the applicable Milestone Date, the Replacement Power provisions contained in Sections 2 and 3 of Appendix G shall apply.
Sample 1
Consequences of Delays. (a) If Seller does not reasonably expect to achieve the Commercial Operation Date by September 1, 2009, Seller shall provide prompt written notice to Purchaser of such expectation, the expected period of delay and the cause of the delay. Seller’s estimate of the expected period of delay shall be based on the best information obtained by Seller, and Seller shall promptly notify Purchaser of any expected changes in such period. Seller shall reimburse Purchaser for any Transportation Costs associated with any change in the anticipated Commercial Operation Date as provided in this Section 3.2; however Eagle will use Commercially Reasonable Efforts to mitigate the cost of any Transportation Costs incurred in connection with this Agreement.
Sample 1
Consequences of Delays. (a) If Seller does not reasonably expect to achieve the Commercial Operation Date by the Delivery Start Date, Seller shall provide prompt written notice thereof not later than ninety (90) Days prior to the Delivery Start Date, (a "Commercial Operation Delay Notice") to Purchaser of such expectation, the expected period of delay and the cause of the delay. Seller's estimate of the expected period of delay shall be based on the best information obtained by Seller, and Seller shall promptly notify Purchaser of any expected changes in such period. Seller shall provide Purchaser with written notice not later than eighty (80) Days prior to the Delivery Start Date as to whether Seller will either (i) elect to be responsible for Replacement Power for the duration of the Commercial Operation Delay Period in accordance with Section 3.2(b), or (ii) elect to incur a Delivery Delay Adjustment for the duration of the Commercial Operation Delay Period in accordance with Section 10.2(a).
Sample 1
AutoNDA by SimpleDocs

Related to Consequences of Delays

  • Consequences of Default Upon the occurrence of any Event of Default, as defined in the Revenue Sharing Agreement:

  • Consequences of Events of Default (i) If an Event of Default has occurred and is continuing, the interest rate on this Note shall increase immediately by an increment of an additional two hundred basis points, to the extent permitted by applicable law. Any increase of the interest rate resulting from the operation of this subparagraph shall terminate as of the close of business on the date on which no Events of Default exist (subject to subsequent increases pursuant to this subparagraph).

  • Consequences of Breach Without prejudice to any rights that may be available to the Principal/Owner under law or the Contract or its established policies and laid down procedures, the Principal/Owner shall have the following rights in case of breach of this Integrity Pact by the Tenderer(s)/Contractor(s) and the Tenderer/ Contractor accepts and undertakes to respect and uphold the Principal/Owner’s absolute right:

  • Consequences of Event of Default In every such event (other than an event with respect to the Borrower described in clause (l) of Section 7.01), and at any time thereafter during the continuance of such event, the Administrative Agent may, and at the request of the Required Lenders shall, by notice to the Borrower, take either or both of the following actions, at the same or different times: (i) terminate the Commitments, and thereupon the Commitments shall terminate immediately, and (ii) declare the Loans then outstanding to be due and payable in whole (or in part, in which case any principal not so declared to be due and payable may thereafter be declared to be due and payable), and thereupon the principal of the Loans so declared to be due and payable, together with accrued interest thereon and all fees and other obligations of the Borrower accrued hereunder, shall become due and payable immediately, without presentment, demand, protest or other notice of any kind, all of which are hereby waived by the Borrower; and in case of any event with respect to the Borrower described in clause (l) of Section 7.01, (i) the Commitments shall automatically terminate, and (ii) the principal of the Loans then outstanding, together with accrued interest thereon and all fees and other obligations of the Borrower accrued hereunder, shall automatically become due and payable, without presentment, demand, protest or other notice of any kind, all of which are hereby waived by the Borrower.

  • Consequences of Non-Delivery After the time at which the Offered Shares are required to be delivered to the Company for transfer to the Company pursuant to subsection (b) above, the Company shall not pay any dividend to the Participant on account of such Offered Shares or permit the Participant to exercise any of the privileges or rights of a stockholder with respect to such Offered Shares, but shall, insofar as permitted by law, treat the Company as the owner of such Offered Shares.

  • Consequences of an Event of Default (a) If an Event of Default specified in subsections (a) through (l), (o), (p) or (q) of Section 7.01 shall occur and, be continuing or shall exist, then, in addition to all other rights and remedies which the Administrative Agent or any Lender may have hereunder or under any other Loan Document, at law, in equity or otherwise, the Lenders shall be under no further obligation to make Loans hereunder, and the Administrative Agent may, and, upon the written request of the Required Lenders shall, by notice to the Borrower, from time to time do any or all of the following:

  • Consequences of a Servicer Default If a Servicer Default shall occur and be continuing, either the Indenture Trustee or the Noteholders whose Notes evidence not less than a majority of the Outstanding Amount of the Controlling Class as of the close of the preceding Distribution Date (or, if the Notes have been paid in full and the Indenture has been discharged in accordance with its terms, by the Owner Trustee or the Majority Certificateholders as of the close of the preceding Distribution Date) by notice then given in writing to the Servicer and the Owner Trustee (and to the Indenture Trustee if given by the Noteholders or the Certificateholders) may terminate all of the rights and obligations of the Servicer under this Agreement. On or after the receipt by the Servicer of such written notice, all authority and power of the Servicer under this Agreement, whether with respect to the Notes, the Certificates or the Receivables or otherwise, shall pass to and be vested in the Indenture Trustee pursuant to and under this Section 7.02. The Indenture Trustee is hereby authorized and empowered to execute and deliver, on behalf of the Servicer, as attorney-in-fact or otherwise, any and all documents and other instruments, and to do or accomplish all other acts or things necessary or appropriate to effect the purposes of such notice of termination, whether to complete the transfer and endorsement of the Receivables and related documents, or otherwise. The Servicer agrees to cooperate with the Indenture Trustee and the Owner Trustee in effecting the termination of the responsibilities and rights of the Servicer under this Agreement, including the transfer to the Indenture Trustee or the Owner Trustee for administration by it of all cash amounts that shall at the time be held by the Servicer for deposit, or that shall have been deposited by the Servicer in the Collection Account, or the Note Distribution Account or thereafter received with respect to the Receivables that shall at that time be held by the Servicer.

  • Consequences of Termination Upon the termination of this Agreement:

  • Voluntariness and Consequences of Consent Denial or Withdrawal The Participant’s participation in the Plan and the Participant’s grant of consent is purely voluntary. The Participant may deny or withdraw his or her consent at any time. If the Participant does not consent, or if the Participant withdraws his or her consent, the Participant cannot participate in the Plan. This would not affect the Participant’s salary as an employee or his or her career; the Participant would merely forfeit the opportunities associated with the Plan.

  • Resolution of Differences Over Breaches of Agreement Except as otherwise provided herein, in the event of any controversy, dispute or claim arising out of, or relating to this Agreement, or the breach thereof, or arising out of any other matter relating to the Employee’s employment with the Company or the termination of such employment, the parties may seek recourse only for temporary or preliminary injunctive relief to the courts having jurisdiction thereof and if any relief other than injunctive relief is sought, the Company and the Employee agree that such underlying controversy, dispute or claim shall be settled by arbitration conducted in Pittsburgh, Pennsylvania in accordance with this Section 11 of this Agreement and the Commercial Arbitration Rules of the American Arbitration Association (“AAA”). The matter shall be heard and decided, and awards rendered by a panel of three (3) arbitrators (the “Arbitration Panel”). The Company and the Employee shall each select one arbitrator from the AAA National Panel of Commercial Arbitrators (the “Commercial Panel”) and AAA shall select a third arbitrator from the Commercial Panel. The award rendered by the Arbitration Panel shall be final and binding as between the parties hereto and their heirs, executors, administrators, successors and assigns, and judgment on the award may be entered by any court having jurisdiction thereof.

Time is Money Join Law Insider Premium to draft better contracts faster.