Conduct of the Work. Contractor shall: • Prior to the start of Work, submit to the Administrator, the Contractor Safety Agreement attached as Exhibit E-1, the Department of Industrial Relations Reporting Form attached as Exhibit E-2, and the Workers Compensation Acknowledgement attached as Exhibit E-3 each signed by an authorized representative of Contractor • Submit all required samples, product data, certificates, operations and maintenance instructions, guarantees, and other submittals no later than five (5) days after the date the City issues a Notice to Proceed. • Ensure all necessary permits and approvals for the Work have been obtained. • Protect all materials to be used in the Work in accordance with the specifications. • Protect existing facilities and personal property. • Remove from the project site all debris resulting from performance of the Work no less often than daily. If Contractor fails to do so, City may, after twenty-four (24) hours' notice to Contractor, clean up the site and deduct the cost from the Contract Price. • For projects scheduled to require more than three (3) days to complete, prepare and submit a written daily activity report to City for each day on which work is performed, including weekends and holidays when worked, and submit the reports to the City no later than the next day that the City is open for business. The daily reports shall, at a minimum, include the following information: construction activities and locations, start or completion of activities, progress on construction activities (including units or portions of work completed), tests or inspections performed, deliveries of material or equipment, delays or potential delays, visitors to the site, weather conditions, construction equipment used, and personal injuries or damage to property. • Unload, hoisting and otherwise handling its own materials, supplies and equipment. • Keep itself fully informed of all applicable laws including existing and future state and federal laws and county and municipal ordinances and regulations which in any manner affect those engaged or employed in the work, or the materials used in the work, or which in any way affect the conduct of work, and of all such orders and decrees of bodies or tribunals having any jurisdiction or authority over the same. • Observe and comply with, and cause all of its agents and employees to observe and comply with, all such applicable laws; and shall protect and indemnify the City, and all elected officials, officers, em...
Conduct of the Work. A. The work must be completed in a continuous uninterrupted operation. The Contractor must use sufficient workforce and adequate equipment to complete all the necessary work requirements within a minimum period of time.
Conduct of the Work. Contractor shall: • Do all things necessary to faithfully perform and complete the Work in a competent manner. • All work shall be performed by experienced personnel directly employed and supervised by the Contractor. The Contractor shall provide management and technical supervision daily through competent supervisor as required. • The Contractor shall be responsible for the skills, methods and actions of all employees. • The Contractor shall cooperate to enable the Administrator to determine the Contractor’s conformity with these specifications and the adequacy of the work being performed. The Contractor shall give personal daily supervision of the work and be available for consultation with the Administrator or an engineer or inspector designated by Administrator. • Submit all required samples, product data, certificates, operations and maintenance instructions, guarantees, and other submittals no later than five (5) days after the date the City issues a Notice to Proceed. • Ensure all necessary permits and approvals for the Work have been obtained. • Protect all materials to be used in the Work in accordance with the specifications. • Protect existing facilities and personal property. • Remove from the project site all debris resulting from performance of the Work no less often than daily. If Contractor fails to do so, City may, after twenty-four (24) hours' notice to Contractor, clean up the site and deduct the cost from the Contract Price. • Unload, hoist and otherwise handle its own materials, supplies and equipment. • Keep itself fully informed of all applicable laws including existing and future state and federal laws and county and municipal ordinances and regulations which in any manner affect those engaged or employed in the work, or the materials used in the work, or which in any way affect the conduct of work, and of all such orders and decrees of bodies or tribunals having any jurisdiction or authority over the same. • Observe and comply with, and cause all of its agents and employees to observe and comply with, all such applicable laws; and shall protect and indemnify the City, and all elected officials, officers, employees, and agents thereof connected with the Work, against any claim or liability arising from or based on the violation of any such law, ordinance, regulation, order, or decree. If any discrepancy or inconsistency is discovered in the plans, drawings, specifications, or contract for the work in relation to any such law, ordina...
Conduct of the Work. Contractor shall: • Prior to the start of Work, submit to the Administrator, the Contractor Safety agreement attached as Exhibit A-2, the Department of Industrial Relations Reporting form attached as Exhibit A-3, and the Workers Compensation Acknowledgement attached as Exhibit A-4 each signed by an authorized representative of Contractor • Submit all required samples, product data, certificates, operations and maintenance instructions, guarantees, and other submittals no later than five (5) days after the date the City issues a Notice to Proceed. • Ensure all necessary permits and approvals for the Work have been obtained. • Protect all materials to be used in the Work in accordance with the specifications. • Protect existing facilities and personal property. • Remove from the project site all debris resulting from performance of the Work no less often than daily. If Contractor fails to do so, City may, after twenty-four
Conduct of the Work. 11.1 SUBCONTRACTOR agrees to be bound by all rules and regulations of Federal, State and local laws, codes And ordinances applicable to the Work.
Conduct of the Work. Except as otherwise provided in this Article XIV, the conditions under which any Work is to be performed and the method of proceeding with and performing the same shall be governed by all of the provisions of Article IX hereof.
Conduct of the Work. Dendreon shall undertake and conduct the work, including the Clinical Trials, as set forth in the Collaboration Research Plan in accordance with appropriate standards articulated in current good clinical practices (GCP), current good manufacturing practices (GMP) and current good laboratory practices (GLP). Dendreon will use reasonable efforts to carry out the work in accordance with the Collaboration Research Plan.
Conduct of the Work. Contractor shall diligently perform the Work, providing sufficient manpower, materials, and other supplies at all times to assure completion of the Work in an orderly fashion by the completion date as specified in the Contract Documents (the “Completion Date”). Contractor shall provide for receipt, unloading, storage, and protection of all materials for the Work, regardless of whether those materials are purchased by Contractor or PCA. Risk of loss for 0 Xxxxx Xxxxx Xxxxx, Xxxx Xxxxxx, XX 00000 (800) 456-4725 xxx.xxxxxxxxxxxxx.xxx those materials remains with Contractor until they are incorporated into the Work. Contractor shall at all times keep the job site reasonably neat and clean and, upon completion of the Work, remove and dispose of all rubbish, trash, and refuse from the Work and leave the job site broom clean. Contractor shall dispose of all materials, waste, and rubbish in compliance with all applicable laws and regulations and shall fulfill all environmental requirements. Contractor shall at all times coordinate its work with and cooperate with the forces of other contractors and subcontractors on the job site and PCA’s own forces. Contractor shall keep confidential all materials marked “Confidential” by PCA.
Conduct of the Work a. Vendor shall apply to Marinvent for any explanation which may be required as to the meaning and intent of any clause in the specifications, terms, conditions and materials of the purchase order and shall be held responsible for any errors or losses consequent upon failure to request such explanation.
Conduct of the Work. In undertaking this work, the service provider will report to the CEO through the Manager, Human Resource. The Manager, human resource as the client will only accept the work once satisfied with the quality of the output.
