CONDITIONS OF CONTRACT. The contractor shall at all times observe and comply with federal and State laws, local laws, ordinances, orders, and regulations existing at the time of or enacted subsequent to the execution of this contract which in any manner affect the completion of the work. The contractor shall indemnify and save harmless the agency and all its officers, representatives, agents, and employees against any claim or liability arising from or based upon the violation of any such law, ordinance, regulation, order or decree by an employee, representative, or subcontractor of the contractor.
CONDITIONS OF CONTRACT. Table of Contents A. General Page No. C. Quality Control Page No. 1 Definitions 38 33. Identifying Defects 46 2 Interpretation 40 34. Tests 46 3 Language and Law 40 35. Correction of Defects 46 4 Engineer's Decisions 40 36. Uncorrected Defects 46 5 Delegation 40 D. Cost Control 47 6 Communications 41 37 Bill of Quantities 47 7 Subcontracting 41 38 Changes in the Quantities 47 8 Other Contractors 41 39 Variations 47 9 Personnel 41 40 Payments for Variations 47 10 Employer’s & Contractor's Risks 41 41 Cash Flow Forecasts 48 11 Employer's Risks 41 42 Payment Certificates 48 12 Contractor’s Risks 42 43 Payments 48 13 Insurance 42 44 Compensation Events 48 14 Site Investigation Reports 42 45 Tax 50 15 Queries about the Contract Data 42 46 Currencies 50 16 Contractor to Construct the Works 42 47 Price Adjustments 50 17 The Works to Be Completed by the Intended Completion Date 43 48 Retention 50 18 Approval by the Engineer 43 49 Liquidated Damages 50 19 Safety 43 50 Bonus 50 20 Discoveries 43 51 Advance Payment 50 21 Possession of the Site 43 52 Securities 51 22 Access to the Site 43 53 Day works 51 23 Instructions 44 54 Cost of Repairs 51 24 Disputes 44 E. Finishing the Contract 52 25 Procedure for Disputes 44 55. Completion 52 26 Replacement of Adjudicator 44 56 Taking Over 52 B. Time Control 44 57 Final Account 52 27 Program 44 58 Operating and Maintenance Manuals 52 28 Extension of the Intended Completion Date 45 59 Termination 52 29 Acceleration 45 60 Payment upon Termination 53 30 Delays Ordered by the Engineer 45 61 Property 53 31 Management Meetings 45 62 Release from Performance 53 32 Early Warning 46 63 Suspension of World Bank Loan or Credit 53 64 Fraud and corruption 54 F. Special Conditions of Contract 55
CONDITIONS OF CONTRACT. Section 3 :
CONDITIONS OF CONTRACT a. This Contract is offered on the condition you are admitted to the University. This Contract does not guarantee you have been admitted to the University. Only the Office of Admissions can grant admission to the University.
CONDITIONS OF CONTRACT. A. General
CONDITIONS OF CONTRACT. Security Deposits Clause 1 :-The person/persons whose tender may be accepted (herein after called the contractor, which expression shall unless excluded by or repugnant to the context include his, heirs, executors, administrators, contractor and assigns) shall (A) within 10 days (which may be extended by the Superintending Engineer concerned, upto 15 days if the Superintending Engineer thinks fit to do so) of the receipt by him of the notification of the acceptance of his tender deposit with the Executive Engineer in cash or Govt. securities endorsed to the Executive Engineer (if deposited for more than 12 months) of sum sufficient which will made up the full security deposit specified in the tender or (B) (Permit Government at the time of making any payment to him for work done under the contract to deduct such as will amount *+ four percent of all moneys so payable such deduction to be held by Government by way of security deposit) provided always that in the event of the contractor depositing a lump sum by way of security deposit as contemplated at (A) above, then and in such case, if the sum so deposited shall not amount to Four percent, of the total estimated cost of the work, it shall be lawful for Government at the time of making any payment to the contractor for work done under the contract to make up the full amount of two percent by deducting a sufficient sum from every such payment as last aforesaid until the full amount of the security deposit is made up. All compensation or other sum of money payable by the contractor to Government under the terms of his Contract may be deducted from or paid by the sale of sufficient part of his security deposit or from the interest arising there from or from any sums which may be due or may become due by Government to the Contractor under any other contract or transaction of any nature on any account whatsoever, and in the event of his security deposit being reduced by reason of any such deduction or sale as aforesaid, the contractor shall, within ten days thereafter, make good in cash or Government securities endorsed as aforesaid any sum or sums which may have been deducted from or raised by sale of his security deposits or any part thereof. The Security Deposit referred to when paid in cash may, at the cost of depositor, be converted into interest bearing securities provided that the depositor has expressly desired this in writing. If the amount of the Security Deposit to be paid in lump sum within the per...
CONDITIONS OF CONTRACT i. Part I General Conditions of Contract and the Contract Data; with all Annexure
CONDITIONS OF CONTRACT. GENERAL CONDITIONS
CONDITIONS OF CONTRACT. 1.0 Short Form of Contract - GENERAL CONDITIONS The conditions of contract are the Conditions of Contract for the Short Form of Contract, First Edition 1999, published by the Federation Internationale des Ingenieurs-Conseils (FIDIC). The General Conditions of Contract are amended by the Particular Conditions of Contract.
CONDITIONS OF CONTRACT. In these conditions the following expressions have the following meanings unless the context otherwise requires, viz.:
