Rental Abatement Provided that any damage to either or both of the Property and the Premises is not caused by, or is not the result of acts or omissions by, any or all of Tenant and Tenant’s Parties, if (a) the Property is damaged by fire or other casualty thereby causing the Premises to be inaccessible or (b) the Premises are partially damaged by fire or other casualty, the Rent shall be proportionally abated to the extent of any actual loss of use of the Premises by Tenant.
No Abatement Except as provided herein, Landlord shall have no liability to Tenant, nor shall Tenant's covenants and obligations under this Lease, including without limitation, Tenant's obligation to pay Annual Basic Rent and Additional Rent, be reduced or abated in any manner whatsoever by reason of any inconvenience, annoyance, interruption or injury to business arising from Landlord's making any repairs or changes which Landlord is required or permitted to make pursuant to the terms of this Lease or by any other tenant's lease or are required by law to be made in and to any portion of the Leased Premises or the Building. Landlord shall, nevertheless, use reasonable efforts to minimize any interference with Tenant's business in the Leased Premises.
Abatement In the event of Premises Partial Damage or Premises Total Destruction or a Hazardous Substance Condition for which Lessee is not responsible under this Lease, the Rent payable by Lessee for the period required for the repair, remediation or restoration of such damage shall be abated in proportion to the degree to which Lessee's use of the Premises is impaired, but not to exceed the proceeds received from the Rental Value insurance. All other obligations of Lessee hereunder shall be performed by Lessee, and Lessor shall have no liability for any such damage, destruction, remediation, repair or restoration except as provided herein.
Rent Abatement Except for the negligence or willful act of Tenant or its agents, employees, contractors or invitees, if all or any part of the Premises are rendered untenantable by fire or other casualty and this Lease is not terminated, Monthly Base Rent and Rent Adjustments shall xxxxx for that part of the Premises which is untenantable on a per diem basis from the date of the casualty until Landlord has Substantially Completed the repair and restoration work in the Premises which it is required to perform, provided, that as a result of such casualty, Tenant does not occupy the portion of the Premises which is untenantable during such period.
No Rent Abatement Tenant shall continue to pay all Rent due or accruing under this Lease during any Clean-up, and shall not be entitled to any reduction, offset or deferral of any Base Rent or Additional Rent due or accruing under this Lease during any such Clean-up.
Base Rent Abatement Provided that no Event of Default is then occurring, then during the period beginning on the Expansion Commencement Date and ending on November 14, 2010 (the “Base Rent Abatement Periods”), Tenant shall not be obligated to pay any Base Rent otherwise attributable to the 6310 Initial Premises for such Base Rent Abatement Period (the “Base Rent Abatement”). Tenant acknowledges and agrees that notwithstanding such Base Rent Abatement, such abatement of Base Rent shall have no effect on the calculation of any future increases in Base Rent, Operating Expenses or Tax Expenses payable by Tenant pursuant to the terms of the Lease (as hereby amended), which increases shall be calculated without regard to such abatement of Base Rent or corresponding abatement periods. Such Base Rent Abatement has been granted to Tenant as additional consideration for entering into this First Amendment, and for agreeing to pay the “rent” and performing the terms and conditions otherwise required under the Lease, as amended. Notwithstanding anything to the contrary set forth in this Section 4.3, to the extent an Event of Default is then occurring, then Landlord may at its option, by notice to Tenant, elect, in addition to any other remedies Landlord may have under the Lease, one or both of the following remedies: (i) that Tenant shall immediately become obligated to pay to Landlord all Base Rent abated hereunder during the Base Rent Abatement Period, with interest as provided pursuant to the Lease from the date such Base Rent would have otherwise been due but for the abatement provided herein, or (ii) that the dollar amount of the unapplied portion of the Base Rent Abatement as of such Event of Default shall be converted to a credit to be applied to the Base Rent applicable to the Premises at the end of the Expansion Term and Tenant shall immediately be obligated to begin paying Base Rent for the entire Premises in full.
No Abatement of Rent This Agreement shall remain in full force and effect and Tenant’s obligation to make all payments of Rent and to pay all other charges as and when required under this Agreement shall remain unabated during the Term notwithstanding any damage involving the Leased Property, or any portion thereof (provided that Landlord shall credit against such payments any amounts paid to Landlord as a consequence of such damage under any business interruption insurance obtained by Tenant hereunder). The provisions of this Article 10 shall be considered an express agreement governing any cause of damage or destruction to the Leased Property, or any portion thereof, and, to the maximum extent permitted by law, no local or State statute, laws, rules, regulation or ordinance in effect during the Term which provide for such a contingency shall have any application in such case.
Inducement Recapture Any agreement for free or abated rent or other charges, or for the giving or paying by Lessor to or for Lessee of any cash or other bonus, inducement or consideration for Lessee's entering into this Lease, all of which concessions are hereinafter referred to as "INDUCEMENT PROVISIONS," shall be deemed conditioned upon Lessee's full and faithful performance of all of the terms, covenants and conditions of this Lease. Upon Breach of this Lease by Lessee, any such Inducement Provision shall automatically be deemed deleted from this Lease and of no further force or effect, and any rent, other charge, bonus, inducement or consideration theretofore abated, given or paid by Lessor under such an Inducement Provision shall be immediately due and payable by Lessee to Lessor, notwithstanding any subsequent cure of said Breach by Lessee. The acceptance by Lessor of rent or the cure of the Breach which initiated the operation of this paragraph shall not be deemed a waiver by Lessor of the provisions of this paragraph unless specifically so stated in writing by Lessor at the time of such acceptance.
Abatement of Rent Notwithstanding anything to the contrary set forth in this Lease, in the event that Tenant is prevented from using, and does not use, the Premises or any portion thereof, as a result of (i) any repair, maintenance or alteration performed by Landlord, or which Landlord failed to perform, after the Lease Commencement Date and required by this Lease, which substantially interferes with Tenant’s use of the Premises, or (ii) any failure to provide services, utilities or access to the Premises as required by this Lease (either such set of circumstances as set forth in items (i) or (ii), above, to be known as an “Abatement Event”), then Tenant shall give Landlord notice of such Abatement Event, and if such Abatement Event continues for five (5) consecutive business days after Landlord’s receipt of any such notice (the “Eligibility Period”), then the Basic Rent, Tenant’s Percentage of Direct Expenses, and Tenant’s obligation to pay for parking (to the extent not utilized by Tenant) shall be abated or reduced, as the case may be, after expiration of the Eligibility Period for such time that Tenant continues to be so prevented from using, and does not use for the normal conduct of Tenant’s business, the Premises or a portion thereof, in the proportion that the rentable area of the portion of the Premises that Tenant is prevented from using, and does not use, bears to the total rentable area of the Premises; provided, however, in the event that Tenant is prevented from using, and does not use, a portion of the Premises for a period of time in excess of the Eligibility Period and the remaining portion of the Premises is not sufficient to allow Tenant to effectively conduct its business therein, and if Tenant does not conduct its business from such remaining portion, then for such time after expiration of the Eligibility Period during which Tenant is so prevented from effectively conducting its business therein, the Basic Rent and Tenant’s Percentage of Direct Expenses for the entire Premises and Tenant’s obligation to pay for parking shall be abated for such time as Tenant continues to be so prevented from using, and does not use, the Premises. If, however, Tenant reoccupies any portion of the Premises during such period, the Rent allocable to such reoccupied portion, based on the proportion that the rentable area of such reoccupied portion of the Premises bears to the total rentable area of the Premises, shall be payable by Tenant from the date Tenant reoccupies such portion of the Premises. To the extent an Abatement Event is caused by an event covered by Articles 23 or 24 of this Lease, then Tenant’s right to xxxxx rent shall be governed by the terms of such Article 23 or 24, as applicable, and the Eligibility Period shall not be applicable thereto. Such right to xxxxx Basic Rent and Tenant’s Percentage of Direct Expenses shall be Tenant’s sole and exclusive remedy for rent abatement at law or in equity for an Abatement Event. Except as provided in this Section 25.5.2, nothing contained herein shall be interpreted to mean that Tenant is excused from paying Rent due hereunder.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
