CONCEALED CONDITIONS. 12.2.1 Should concealed conditions encountered in the performance of the Work below the surface of the ground, or should concealed or unknown conditions in an existing structure be at variance with the conditions indicated by the Contract Documents or should unknown physical conditions below the surface of the ground or should concealed or unknown conditions in an existing structure of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in this Contract, be encountered, the Contract Sum shall be equitably adjusted by Change Order upon claim by either party made within twenty days after the first observance of the conditions.
CONCEALED CONDITIONS. 8.5.1 If conditions are encountered at the site which are (1) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents, or (2) unknown physical conditions of an unusual nature which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, then notice by the observing party shall be given to the other party promptly before conditions are disturbed and in no event later than 21 days after first observance of the conditions. The Contract Sum shall be equitably adjusted for such concealed or unknown conditions by Change Order upon claim by either party made within 21 days after the claimant becomes aware of the conditions.
CONCEALED CONDITIONS. 11.1.1. Adjustment of Contract Sum or Contract Time
CONCEALED CONDITIONS a. Contract Drawings showing the approximate location of existing and new utility lines, if any, have been identified and located as accurately as possible using readily available information. However, the Contractor is responsible for verifying the accuracy of all locations. If utilities require relocation or rerouting Contractor shall notify the Village and cooperate with the Village to make the required adjustments.
CONCEALED CONDITIONS. If defects are discovered in the course of Service, that were not apparent on initial inspection of the Equipment, the Seller shall inform the Buyer about the additional Service and the costs thereof. The Seller will not perform the additional Service without a Change Order as per paragraph 6. The parties acknowledge and agree that increased costs or schedule extensions due to any concealed conditions at the job site or other events and circumstances coming from the Buyer's sphere of influence including strikes of his personnel shall be to Buyer's account.
CONCEALED CONDITIONS. The parties acknowledge and agree that increased costs or schedule extensions due to any concealed conditions at the job site or other events and circumstances coming for the Buyer's sphere of influence including strikes of personnel not in our employ shall be to Buyer's account. Buyer shall hold Seller harmless for increased costs and grant any necessary schedule extensions if any concealed or hazardous conditions are found.
CONCEALED CONDITIONS. SHOULD CONCEALED OR UNKNOWN CONDI- TIONS BELOW THE SURFACE OF THE GROUND OR CONCEALED OR UNKNOWN CONDI- TIONS IN AN EXISTING STRUCTURE, BE ENCOUNTERED WHICH ARE AT VARIANCE WITH THE CONDITIONS INDICATED BY THE CONTRACT DOCUMENTS, OR BE OF AN UNUSUAL NATURE, DIFFERING MATERIALLY FROM THOSE ORDINARILY ENCOUN- TERED AND GENERALLY RECOGNIZED AS INHERENT IN WORK OF THE CHARACTER PROVIDED FOR IN THIS CONTRACT, CONTRACTOR SHALL GIVE IMMEDIATE WRITTEN NOTICE THEREOF TO OWNER AND THE CONTRACT SUM SHALL BE AMENDED BY CHANGE ORDER UPON CLAIM BY EITHER OWNER OR CONTRACTOR WITHIN SEVEN (7) DAYS AFTER THE FIRST OBSERVANCE OF THE CONDITIONS.
CONCEALED CONDITIONS. If, during or after the Site Survey, we discover any concealed or hidden conditions or issues with the Home that may delay or prevent completion of the Solar System once we start installation, we will explain the issue to you, determine if additional costs are required to correct the problem and, if so, propose a change order. It may be necessary that you undertake site preparation prior to installation.
CONCEALED CONDITIONS. Prior to the Full Operations Date, Lessee may suspend its performance of its obligations under this Agreement if it encounters Concealed Conditions at the Premises.
CONCEALED CONDITIONS. Contractor shall promptly notify the Owner of: 1) latent physical conditions at the job site differing materially from those indicated in the contract, or 2) unknown physical conditions differing materially from those ordi- narily encountered and generally recognized as inherent in work of the character provided for in this contract. Any expense incurred due to such conditions shall be paid for by the Owner as added work and may change the type of contract required for the job. Delays: Contractor agrees to start and pursue work through to its completion, but shall not be responsible for delays for and of the following reasons: failure of the issuance of all necessary building permits within a reasonable period of time; acts of neglect or omission by Owner or Owner’s employees or agents; acts of God; weather delays; strikes, lockouts, boycotts or other labor union activities; extra work ordered by Owner; acts of criminals, riots or civil commotion; inability to secure material through regular recognized channels; imposition of Government priority or allocation of material; failure of Owner to make payments when due; delays caused by inspection or changes ordered by the inspectors of government bodies; acts of independent Contractors; holidays; or other causes beyond this Contractor’s rea- sonable control. Xxxx, Taxes, and Assessments: Taxes, Permits, Fees, and Assessments of all descriptions will be paid by Owner. Contractor will obtain all required building per- mits, at the sole expense of the Owner. Upon demand by Contractor, Owner shall provide funds to acquire any and all necessary permits in a timely fashion. Owner will pay assessments and charges required by public bodies and utilities for financ- ing or repaying the cost of sewers, storm drains, water service, schools and school facilities, other utilities, hook-up charges and the like. Payments and Right to Stop Work: Contractor shall have the right to stop work if any payment shall not be made to Contractor when due under this agreement. Contractor may keep the job idle until all payments due are received. In the event that collection efforts are initiated against Owner, Owner agrees to pay for all asso- ciated fees at the posted rates. If any check received from Owner does not clear our bank, Owner can be held liable for three times the amount of the check, up to $500, not less than $100, plus the face value of the check, as set forth on California Civil Code Section 1719. These remedies are in a...
