Completion of the Works. (a) Project Co shall complete the Works in accordance with this Project Agreement and achieve:
Completion of the Works. 22.1.1. The Contractor must bring the Works to Practical Completion by the Date for Practical Completion.
Completion of the Works. 15.1 When, in the reasonable opinion of the Employer’s Representative, the Works in any Contract Order are practically complete, the Employer’s Representative shall issue a certificate to that effect and Practical Completion of the Works shall occur on the day named in such certificate. Such certificate may also be accompanied by a list of items of work which are, in the Employer’s Representative’s opinion, required to render the Works entirely completed. The Contractor shall with all due diligence complete any such items of work.
Completion of the Works. The Works or sections or parts thereof, shall be deemed to be completed only when the Works, sections or part thereof in the opinion of LOST is fully completed and a Taking- Over Certificate has been issued. The Taking-Over Certificate shall not be issued until:
Completion of the Works. 11.1 The Borrower agrees to complete the Works by:
Completion of the Works. 3.1 The Works will commence on the agreed start date and shall be completed by the agreed completion date. If it becomes clear that the Contractor will not be able to complete the work by the agreed date then the Contractor shall inform Solarcentury as soon as practicable. Solarcentury may, in its absolute discretion, agree to such extension of time as it considers reasonable.
Completion of the Works. 14.2.1. Upon successful completion of the Works and handing over of the Systems (milestone no. 16), and subject to a successful completion of all other actions specified as requirements for Final Completion in the Technical Specifications, the IAA shall issue the Supplier a completion certificate (the "Completion Certificate"). After achieving the Time of Completion, the Supplier may be granted, at the IAA’s sole discretion, the authorization to begin the OMP.
Completion of the Works. 20.1 On completion of the works, the Contractor shall remove all the remaining construction plant and material from the site, other than material which is the property of the network operator, and leave the site in a clean, neat and tidy condition. If material and plant is required for the liability and maintenance period the Contract supervisor must authorise it’s retention on site.
Completion of the Works. 12.1 When, in the opinion of the Designated Officer, the Trade Contract Works are practically complete, the Designated Officer shall issue the Certificate of Satisfaction (or make final payment), and the Trade Contract Works shall be treated as having been completed for all purposes of this Agreement on the date of the Certificate (or payment).
Completion of the Works the Buyer must notify the Seller as soon as the Works have been completed following which the Seller will carry out a Final Inspection. If, following the Final Inspection, the Seller reasonably considers the Works have been completed to the satisfaction of the Seller, the Seller shall provide the Buyer with a Certificate of Practical Completion and confirm that the sale of the Property to the Buyer can take effect within 10 working days of the date of the Certificate of Practical Completion. If, following the Final Inspection, the Seller does not consider the Works have been completed to the required standard, the Seller shall provide the Buyer with a list of Additional Works to be carried out and the reasonable date by which the Additional Works should be completed. If for any reason the parties are unable to agree the Additional Works required then the parties hereto agree to accept as arbitrator a person appointed by agreement between the parties or alternatively either party may apply to the President of the Royal Institution of Chartered Surveyors to make an appointment of a single arbitrator in accordance with the Arbitration Xxx 0000 and any subsequent amending legislation. The fees and expenses of the Arbitrator, including the cost of its nomination, are to be borne as the expert determines. If following completion of the Additional Works the Seller considers the Additional Works have been completed to the required standard, the Seller shall provide the Buyer with a Certificate of Practical Completion and confirm that the sale of the Property to the Buyer can take effect within 10 working days of the date of the Certificate of Practical Completion. If the Buyer fails to complete the Additional Works by the date specified by the Seller, then the Buyer shall return the Property to the Seller’s Solicitors and the Seller may serve notice in writing on the Buyer’s solicitors rescinding this Agreement. The Buyer shall not be entitled to recover from the Seller any costs incurred by the Buyer in carrying out any of the Works or Additional Works If the Agreement is rescinded by the Seller, the Buyer shall remove all personal or the Works and if so required the Additional Works related possessions from the Property immediately. If any of the Buyer's possessions are left at the Property the Buyer will be responsible for meeting all reasonable removal and storage charges. If the items are not collected within two weeks of Agreement being rescinded, the Seller...
