COMPLETION OF THE CONTRACT. Extension of Contract Period - If it becomes apparent that the works will not be completed by the date outlined for completion in Article 2 of the Small Contract Agreement for reasons beyond the Contractor's control, then the Contractor shall so notify the Department Representative who shall make, in writing, such extension of time for completion as is reasonable. Liquidated Damages - If the Works are not substantially completed by the date outlined in Article 2 then the Contractor shall pay the Owner liquidated damages at the rate outlined in Article 2 for such payments. Retention - A five per cent (5%) retention of the total Contract Sum will be withheld by the Owner for a warranty period of thirty (30) days after substantial completion as a remedy for any latent defects due to workmanship which may appear during this period. Retained funds not required due to satisfactory workmanship shall be released to the Contractor at the close of the warranty period. Substantial Completion - The Department Representative shall certify the date when in their opinion the Works are substantially complete. Arbitration - Any dispute between the parties arising from this contract shall be dealt with by Arbitration in accordance with the Arbitration Act 1986.
COMPLETION OF THE CONTRACT. 3.1 The Contract is concluded with the signing of the Offer / Order Proposal for Products and Services, or acceptance of the same, expressed by any traceable means, including electronic, suitable for proving the origin, by the Customer; or with the sharing between the Parties of changes to the Offer / Order proposal for Products and Services formulated by SMEUP ICS, in any way traced. The acceptance of the Offer / Order Proposal for Products and Services by the Customer, or the request for changes or additions shared between the Parties, imply and imply the knowledge and full acceptance by the Customer of the contents of all the documents constituting the Contract. Any early activation of the Services, or order to the supplier of the Products, by SMEUP ICS, at the request of the Customer, does not exempt the same from the signing and sending of acceptance of the Offer / Order Proposal for Products and Services, without prejudice it being understood that SMEUP ICS is in any case authorized to invoice the Services rendered from the date of their activation, or the Products supplied from the date of the order and the Customer, from that date, will be bound and subject to the agreements contained in the Contract.
COMPLETION OF THE CONTRACT. This Treaty shall apply regardless of whether diplomatic or consular relations exist between the Contracting States.
COMPLETION OF THE CONTRACT. By regulation, the contract of participation is considered to be completed, and a family’s participation in the FSS program is considered to be concluded when one of the following occurs [24 CFR 984.303(g)]: • The FSS family has fulfilled all of its obligations under the contract of participation on or before the expiration of the contract term, including any extension thereof. • 30 percent of the monthly adjusted income of the FSS family equals or exceeds the published existing housing fair market rent for the size of the unit for which the FSS family qualifies based on the PHA’s occupancy standards. The contract of participation will be considered completed and the family’s participation in the FSS program concluded on this basis even though the contract term, including any extension thereof, has not expired, and the family members who have individual training and services plans have not completed all the activities set forth in their plans. Policies on verifying completion of the contract of participation can be found in Section 6-I.C. of this action plan.
COMPLETION OF THE CONTRACT. 78. Completion 78.1 The Contractor shall apply by notice to the Project Manager for issuing a Completion Certificate of the Works, and the Project Manager shall do so upon deciding that the work is completed.
COMPLETION OF THE CONTRACT. The Contractor acknowledges and agrees to complete the Services no later than Date. Following the effective date of this Contract, the City shall issue the Contractor a written Notice to Proceed, after which the Contractor acknowledges and agrees to complete the Services within XX calendar days of receipt thereof, unless a later date is specified by the City in the Notice to Proceed. L Following the effective date of this Contract, the City shall, for ongoing requests for Services, issue the Contractor a request for specified Services (“Request”). The Contractor shall reply to that Request within XX calendar days with proposed costs, timelines and other details delineated in the Request to provide the specified Services. If the City accepts the proposal, the City shall issue the Contractor a written Notice to Proceed, after which the Contractor acknowledges and agrees to complete the Services within XX calendar days thereafter, unless a later date is specified by the City in the Notice to Proceed.
COMPLETION OF THE CONTRACT. The Completion of the Contract shall control as to any issue that may arise regarding the particular point in time when a Contractor may be barred from recovering against the State as provided under N.J.S.A. 59:13-5 et seq. The Contractual Claims Resolution Process and the various steps thereof may continue beyond the Completion of the Contract; however, the Contractual Claims Resolution Process will not in any manner, expressed or implied, extend any statute of limitation that may apply as to a claim. The Contractor by entering into the Contract with the Department agrees no further notice to the Contractor regarding the provisions stated in this Section are required. The Contractor also agrees to be responsible for compliance with all statutes of limitation and compliance with the various provisions of the Contractual Liability Act, N.J.S.A. 59:13-1 et seq.
COMPLETION OF THE CONTRACT. 1. The written notification of renewal or completion of employment shall be provided two months (60 days) prior to the expiration of the Contract.
COMPLETION OF THE CONTRACT. Following the end of a normal term, the Depositor will be required to pick up their Goods on or before the end of term date. If Goods remain following the end of term, the Depositor will be charged a $10.00 fee per day for each day the Goods remain within the Storage Facility. If Goods are not picked up within 90 days of the completion of the contract, the Depositor will be considered to have abandoned the Goods, and irrevocably assign the Goods to Canoe Self Storage, for the purpose of sale.
COMPLETION OF THE CONTRACT. Extension of Contract Period - If it becomes apparent that the works will not be completed by the date outlined for completion in Article 2 of the Small Contract Agreement for reasons beyond the Contractor's control, then the Contractor shall so notify the project officer who shall make, in writing, such extension of time for the completion as is reasonable. Substantial Completion - The project officer shall certify the date when in his opinion the contract works are substantially complete. Arbitration - any dispute between the parties arising from this contract shall be dealt with by Arbitration in accordance with the Arbitration Act 1986.The decision of the Arbitrator is to be final save as to a point of law.
