Completion of Outstanding Work and Remedying Defects Sample Clauses

Completion of Outstanding Work and Remedying Defects. In order that the Works and Contractor's Documents, and each Section, shall be in the condition required by the Contract (fair wear and tear excepted) by the expiry date of the relevant Defects Notification Period or as soon as practicable thereafter, the Contractor shall:
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Completion of Outstanding Work and Remedying Defects. To the intent that the Works shall, at or as soon as practicable after the expiration of the Defects Liability Period, be delivered to the Employer in the condition required by the Contract, fair wear and tear excepted, to the satisfaction of the Engineer, the Contractor shall
Sample 1Sample 2Sample 3
Completion of Outstanding Work and Remedying Defects. In order that the Works and Contractor’s Documents, and each Section, shall be in the condition required by the Contract (fair wear and tear excepted) by the expiry date of the relevant Defects Notification Period or as soon as practicable thereafter, the Contractor shall: complete any work which is outstanding on the date stated in a Taking-Over Certificate, within such reasonable time as is instructed by the Engineer, and execute all work required to remedy defects or damage, as may be notified by (or on behalf of) the Procuring entity on or before the expiry date of the Defects Notification Period for the Works or Section (as the case may be). If a defect appears or damage occurs, the Contractor shall be notified accordingly, by (or on behalf of) the Procuring entity. Cost of Remedying Defects All work referred to in sub-paragraph (b) of Sub-Clause 11.1 [Completion of Outstanding Work and Remedying Defects] shall be executed at the risk and cost of the Contractor, if and to the extent that the work is attributable to: any design for which the Contractor is responsible, Plant, Materials or workmanship not being in accordance with the Contract, or failure by the Contractor to comply with any other obligation. If and to the extent that such work is attributable to any other cause, the Contractor shall be notified promptly by (or on behalf of) the Procuring entity and Sub-Clause 13.3 [Variation Procedure] shall apply. Extension of Defects Notification Period The Procuring entity shall be entitled subject to Sub-Clause 2.5 [Procuring entity’s Claims] to an extension of the Defects Notification Period for the Works or a Section if and to the extent that the Works, Section or a major item of Plant (as the case may be, and after taking over) cannot be used for the purposes for which they are intended by reason of a defect or by reason of a damage attributable to the Contractor. However, a Defects Notification Period shall not be extended by more than two years. If delivery and/or erection of Plant and/or Materials was suspended under Sub-Clause 8.8 [Suspension of Work] or Sub-Clause 16.1 [Contractor’s Entitlement to Suspend Work], the Contractor’s obligations under this Clause shall not apply to any defects or damage occurring more than two years after the Defects Notification Period for the Plant and/or Materials would otherwise have expired. Failure to Remedy Defects If the Contractor fails to remedy any defect or damage within a reasonable time but not excee...
Sample 1
Completion of Outstanding Work and Remedying Defects. (a) The Contractor shall, during the Defects Liability Period complete with due expedition or within such time as may be specified by the Superintending Officer, any work outstanding at the Date of Practical Completion (whether or not the Contractor has undertaken to do so). Completion of Outstanding Work and Remedying Defects
Sample 1
Completion of Outstanding Work and Remedying Defects. 完成扫尾工作和修补缺陷 In order that the Works and Contractor’s Documents, and each Section ,shall be in the condition required by the Contract (fair wear and tear excepted) by the expiry date of the relevant Defects Notification Period or as soon as practicable thereafter, the Contractor shall: 为了使工程、承包商文件和每个分项工程在相应缺陷通知期限期满日期或其后尽快达到合同要求(合理的损耗除外),承包商应: （a） complete any work which is outstanding on the date stated in a Taking-Over Certificate, within such reasonable time as is instructed by the Employer, and 在雇主指示的合理时间内,完成接收证书注明日期时尚未完成的任何工作； （b） execute all work required to remedy defects or damage, as may be notified by the Employer on or before the expiry date of the Defects Notification Period for the Works or Section (as the case may be) 在工程或分项工程(视情况而定)的缺陷通知期限期满日期或其以前,按照雇主可能通知的要求,完成修补缺陷或损害所需要的所有工作。 If a defect appears or damage occurs, the Employer shall notify the Contractor accordingly. 如果出现缺陷,或发生损害,雇主应根据情况,通知承包商。
Sample 1
Completion of Outstanding Work and Remedying Defects. (a) At any time during the Defects Liability Period as stated in Appendix hereto (or if none stated the period is twelve (12) months from the date of practical completion of the Works), any defect, imperfection, shrinkage or any other fault whatsoever which may appear and which are due to materials or goods or workmanship not in accordance with this Contract, the S.O. shall issue written instruction to the Contractor to make good such defects, imperfections, shrinkages or any other fault whatsoever at the Contractor's own cost. The Contractor shall complete all such works with due expedition or within such time as may be specified by the S.O.
Sample 1

Related to Completion of Outstanding Work and Remedying Defects

  • Landlord’s Default and Tenant’s Remedies In the event Landlord fails to perform its obligations under this Lease, Landlord shall nevertheless not be in default under the terms of this Lease until such time as Tenant shall have first given Landlord written notice specifying the nature of such failure to perform its obligations, and then only after Landlord shall have had thirty (30) days following its receipt of such notice within which to perform such obligations; provided that, if longer than thirty (30) days is reasonably required in order to perform such obligations, Landlord shall have such longer period. In the event of Landlord’s default as above set forth, then, and only then, Tenant may then proceed in equity or at law to compel Landlord to perform its obligations and/or to recover damages proximately caused by such failure to perform (except as and to the extent Tenant has waived its right to damages as provided in this Lease).

  • Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.

  • Landlord’s Remedies If an Event of Tenant’s Default occurs, Landlord shall have the following remedies, in addition to all other rights and remedies provided by any Law or otherwise provided in this Lease, to which Landlord may resort cumulatively or in the alternative:

  • Default and Remedies Either of the following constitutes cause to declare this Contract, or any Participating Entity order under this Contract, in default:

  • Defaults and Remedies Section 6.01.

  • Landlord Remedies The remedies provided Landlord under this Lease are cumulative. Upon the occurrence of any default by Tenant, and in addition to any and all other rights provided a landlord under law or equity for breach of a lease or tenancy by a tenant, Landlord shall have the right to pursue one or more of the following remedies:

  • Waiver and Remedies The parties may (a) extend the time for performance of any of the obligations or other acts of any other party to this Agreement, (b) waive any inaccuracies in the representations and warranties of any other party to this Agreement contained in this Agreement or in any certificate, instrument or document delivered pursuant to this Agreement or (c) waive compliance with any of the covenants, agreements or conditions for the benefit of such party contained in this Agreement. Any such extension or waiver by any party to this Agreement will be valid only if set forth in a written document signed on behalf of the party or parties against whom the waiver or extension is to be effective. No extension or waiver will apply to any time for performance, inaccuracy in any representation or warranty, or noncompliance with any covenant, agreement or condition, as the case may be, other than that which is specified in the written extension or waiver. No failure or delay by any party in exercising any right or remedy under this Agreement or any of the documents delivered pursuant to this Agreement, and no course of dealing between the parties, operates as a waiver of such right or remedy, and no single or partial exercise of any such right or remedy precludes any other or further exercise of such right or remedy or the exercise of any other right or remedy. Any enumeration of a party’s rights and remedies in this Agreement is not intended to be exclusive, and a party’s rights and remedies are intended to be cumulative to the extent permitted by law and include any rights and remedies authorized in law or in equity.

  • Powers and Remedies Cumulative; Delay or Omission Not Waiver of Default Except as provided in Section 5.6, no right or remedy herein conferred upon or reserved to the Trustee or to the Holders of Securities or Coupons is intended to be exclusive of any other right or remedy, and every right and remedy shall, to the extent permitted by law, be cumulative and in addition to every other right and remedy given hereunder or now or hereafter existing at law or in equity or otherwise. The assertion or employment of any right or remedy hereunder, or otherwise, shall not prevent the concurrent assertion or employment of any other appropriate right or remedy. No delay or omission of the Trustee or of any Holder of Securities or Coupons to exercise any right or power accruing upon any Event of Default occurring and continuing as aforesaid shall impair any such right or power or shall be construed to be a waiver of any such Event of Default or an acquiescence therein; and, subject to Section 5.6, every power and remedy given by this Indenture or by law to the Trustee or to the Holders of Securities or Coupons may be exercised from time to time, and as often as shall be deemed expedient, by the Trustee or by the Holders of Securities or Coupons.

  • Waiver; Deficiency Each Grantor waives and agrees not to assert any rights or privileges which it may acquire under Section 9-112 of the New York UCC. Each Grantor shall remain liable for any deficiency if the proceeds of any sale or other disposition of the Collateral are insufficient to pay its Obligations and the fees and disbursements of any attorneys employed by the Administrative Agent or any Lender to collect such deficiency.

Time is Money Join Law Insider Premium to draft better contracts faster.