Completion of Construction Work. Upon Substantial Completion of the Project, Tenant shall furnish the FCRHA with (a) a certification of the Architect (certified to the FCRHA) that it has examined the applicable plans and specifications (that shall include the Plans and Specifications in the case of Initial Construction Work or a Restoration of the Project) and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Construction Work has been substantially completed in accordance with the plans and specifications applicable thereto and, as constructed, the Project complies with all applicable Requirements, (b) if required, a copy or copies of the temporary or permanent certificate(s) of occupancy for the Project issued by the Fairfax County Department of Public Works and Environmental Services (or such other appropriate Governmental Authority), and (c) with respect to the Initial Construction Work (or a Restoration) of the Project, within ninety (90) days of Substantial Completion, a complete set of “as built” plans, in either CADD format, to the extent available, or in field marked copies of the plans, and a survey showing the Project. The FCRHA shall have an unrestricted non-exclusive license to use such “as built” plans and survey for any purpose without paying any additional cost or compensation therefor, which license shall be subject to the rights of the parties preparing such plans and survey under copyright and other applicable laws.
Completion of Construction Work. Upon Final Completion of the Project, Tenant shall furnish Landlord with (a) a certification of the Architect (certified to Landlord) that it has examined the applicable plans and specifications (that shall include the Plans and Specifications in the case of Initial Construction Work or a Restoration of the Project) and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Construction Work has been completed in accordance with the plans and specifications applicable thereto and, as constructed, the Project complies with all Applicable Laws, (b) if required, a copy or copies of the temporary or permanent certificate(s) of occupancy for the Project issued by the Fairfax County Department of Planning and Development (or such other appropriate Governmental Authority), and (c) with respect to the Initial Construction Work (or a Restoration for which “as built” plans will be issued) of the Project, within ninety (90) days after Substantial Completion, a complete set of “as built” plans and a survey showing the Project. Landlord shall have an unrestricted non-exclusive license to use such “as built” plans and survey in connection with any Restoration of the Project without paying any additional cost or compensation therefor, which license shall be subject to the rights of the parties preparing such plans and survey under copyright and other applicable laws.
Completion of Construction Work. The following procedures shall govern all issues of incomplete construction work which are not specifically addressed elsewhere in this Agreement:
Completion of Construction Work. In case of a plot / land, the construction shall be completed within 2 years and in case of a shed / stall / built-up space, the construction / preparation shall be completed within 1 year from the date of execution of the Deed of Assignment or delivery of possession, whichever is earlier. If there is any delay in completion of the construction or the preparatory work, on justifiable reasons beyond the control of the Assignee, the Assignor may allow such extension as deemed fit and proper.
Completion of Construction Work. Upon substantial completion of a Restoration or a Capital Improvement having a total cost in excess of $250,000, Tenant shall furnish Administrator with (a) a certification of the architect or a licensed professional engineer acceptable to Administrator (certified to Landlord and Administrator) that it has examined the applicable plans and specifications and that, in its best professional judgment, after diligent inquiry, to its best knowledge and belief, the Restoration or the Capital Improvement, as the case may be, has been substantially completed in accordance with the plans and specifications applicable thereto and, as constructed, the Restoration or Capital Improvement, as the case may be, complies with the Building Code of New York City and all other Requirements, (b) a copy or copies of the temporary or permanent (whichever is applicable, if any) Certificate(s) of Occupancy for the relevant portion of the Premises, (c) copies of official certificates evidencing compliance with all Requirements, if any and (d) the most current set of available architectural plans. Tenant shall further furnish Administrator with a complete set of “as built” plans, as of the date a temporary or permanent (whichever is applicable) Certificate of Occupancy is issued, as soon as such are prepared, but in no event later than thirty (30) days after a temporary or permanent (as applicable) Certificate of Occupancy is issued. Administrator shall have a, non-exclusive, irrevocable license to use such “as built” plans and survey for the purpose of completing the Work on the Premises without paying any additional cost or compensation therefor, subject to copyright and similar rights under applicable law of the architect and other Persons who prepared such plans and surveys.
