Completion Audit Settlement and Closeout
Completion Audit Settlement and Closeout Sample Clauses
Related to Completion Audit Settlement and Closeout
RECORD RETENTION AND INSPECTION/AUDIT SETTLEMENT The Contractor shall maintain accurate and complete financial records of its activities and operations relating to this Contract in accordance with generally accepted accounting principles. The Contractor shall also maintain accurate and complete employment and other records relating to its performance of this Contract. The Contractor agrees that the County, or its authorized representatives, shall have access to and the right to examine, audit, excerpt, copy, or transcribe any pertinent transaction, activity, or record relating to this Contract. All such material, including, but not limited to, all financial records, bank statements, cancelled checks or other proof of payment, timecards, sign-in/sign-out sheets and other time and employment records, and proprietary data and information, shall be kept and maintained by the Contractor and shall be made available to the County during the term of this Contract and for a period of five (5) years thereafter unless the County’s written permission is given to dispose of any such material prior to such time. All such material shall be maintained by the Contractor at a location in Los Angeles County, provided that if any such material is located outside Los Angeles County, then, at the County’s option, the Contractor shall pay the County for travel, per diem, and other costs incurred by the County to examine, audit, excerpt, copy, or transcribe such material at such other location.
Project Closeout a. Participate in final inspection to prepare punch lists for project contractor to correct and/or to complete listed items. Verify that items on punch lists have been completed successfully assist COUNTY Project Manager or designee to determine completion date and coordinate project close out.
Contract Closeout Prior to the contract’s expiration date, Supplier may be provided contract close out documentation and shall complete, sign and return to VITA Supply Chain Management within 30 days of receipt. This documentation may include, but not be limited to: Patent/Royalty Certificate, Tangible Property/Asset Certificate, Escrow Certificate, SWaM Subcontracting Certification of Compliance, Sales Reports/IFA Payments Completion Certificate, and Final Payment Certificate. Supplier is required to process these as requested to ensure completion of close-out administration and to maintain a positive performance reputation with the Commonwealth of Virginia. Any closeout documentation not received within 30 days of Supplier’s receipt of the Commonwealth's request will be documented in the contract file as Supplier non-compliance. Supplier’s non-compliance may affect any pending payments due the Supplier, including final payment, until the documentation is returned.
Inspection & Audit Contractor agrees that the relevant books, records (written, electronic, computer related or otherwise), including, without limitation, relevant accounting procedures and practices of Contractor or its subcontractors, financial statements and supporting documentation, and documentation related to the work product shall be subject, at any reasonable time, to inspection, examination, review, audit, and copying at any office or location of Contractor where such records may be found, with or without notice by the City, and with regard to any federal funding, the relevant federal agency, the Comptroller General, the General Accounting Office, the Office of the Inspector General, or any of their authorized representatives. All subcontracts shall reflect the requirements of this paragraph.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
PRICE ESCALATION/DE-ESCALATION (CPI) The County may allow a price escalation provision within this award. The original contract prices shall be firm for an initial one (1) year period. A price escalation/de-escalation will be considered at one (1) year intervals thereafter, provided the Contractor notifies the County, in writing, of the pending price escalation/de-escalation a minimum of sixty (60) days prior to the effective date. Price adjustments shall be based on the latest version of the Consumers Price Index (CPI-U) for All Urban Consumers, All Items, U.S. City Average, non-seasonal, as published by the U.S. Department of Labor, Bureau of Labor Statistics. This information is available at xxx.xxx.xxx. Price adjustment shall be calculated by applying the simple percentage model to the CPI data. This method is defined as subtracting the base period index value (at the time of initial award) from the index value at time of calculation (latest version of the CPI published as of the date of request for price adjustment), divided by the base period index value to identify percentage of change, then multiplying the percentage of change by 100 to identify the percentage change. Formula is as follows: Current Index – Base Index / Base Index = % of Change % of Change x 100 = Percentage Change CPI-U Calculation Example: CPI for current period 232.945 Less CPI for base period 229.815 Equals index point change 3.130 Divided by base period CPI 229.815 Equals 0.0136 Result multiplied by 100 0.0136 x 100 Equals percent change 1.4% A price increase may be requested only at each time interval specified above, using the methodology outlined in this section. To request a price increase, Contractor shall submit a letter stating the percentage amount of the requested increase and adjusted price to the Orange County Procurement Division. The letter shall include the complete calculation utilizing the formula above, and a copy of the CPI-U index table used in the calculation. The maximum allowable increase shall not exceed 4%, unless authorized by the Manager, Procurement Division. All price adjustments must be accepted by the Manager, Procurement Division and shall be memorialized by written amendment to this contract. No retroactive contract price adjustments will be allowed. Should the CPI-U for All Urban Consumers, All Items, U.S City Average, as published by the U.S. Department of Labor, Bureau of Labor Statistics decrease during the term of the contract, or any renewals, the Contractor shall notify the Orange County Procurement Division of price decreases in the method outlined above. If approved, the price adjustment shall become effective on the contract renewal date. If the Contractor fails to pass the decrease on to the County, the County reserves the right to place the Contractor in default, cancel the award, and remove the Contractor from the County Vendor List for a period of time deemed suitable by the County. In the event of this occurrence, the County further reserves the right to utilize any options as stated herein.
Commercial Settlement All the commercial settlements under this agreement shall be as per Government of Gujarat’s Solar Power Policy 2015 and Order No. 3 of 2015 dated 17.08.2015 of the Gujarat Electricity Regulatory Commission and any subsequent orders in this regard. The commercial settlement will be as follows:
PRELIMINARY APPROVAL OF SETTLEMENT 3. Promptly upon execution of this Stipulation, Lead Plaintiffs will move for preliminary approval of the Settlement, certification of the Settlement Class for settlement purposes only, and the scheduling of a hearing for consideration of final approval of the Settlement, which motion shall be unopposed by Defendants. Concurrently with the motion for preliminary approval, Lead Plaintiffs shall apply to the Court for, and Defendants shall agree to, entry of the Preliminary Approval Order, substantially in the form attached hereto as Exhibit A. RELEASE OF CLAIMS
OIG INSPECTION, AUDIT, AND REVIEW RIGHTS In addition to any other rights OIG may have by statute, regulation, or contract, OIG or its duly authorized representative(s) may conduct interviews, examine or request copies of Xxxxxx’x books, records, and other documents and supporting materials and/or conduct on-site reviews of any of Xxxxxx’x locations for the purpose of verifying and evaluating: (a) Xxxxxx’x compliance with the terms of this IA and (b) Xxxxxx’x compliance with the requirements of the Federal health care programs. The documentation described above shall be made available by Xxxxxx to OIG or its duly authorized representative(s) at all reasonable times for inspection, audit, and/or reproduction. Furthermore, for purposes of this provision, OIG or its duly authorized representative(s) may interview Xxxxxx and any of Xxxxxx’x employees or contractors who consent to be interviewed at the individual’s place of business during normal business hours or at such other place and time as may be mutually agreed upon between the individual and OIG. Xxxxxx shall assist OIG or its duly authorized representative(s) in contacting and arranging interviews with such individuals upon OIG’s request. Xxxxxx’x employees and contractors may elect to be interviewed with or without a representative of Xxxxxx present.
Monetary Settlement Terms 3.1 Civil Penalty Payment
