Compensation to Contractor The terms related to the price of the goods and/or services to be provided under this Agreement and the terms of payment to the Contractor are described in more detail in Attachment “B” to this Agreement: Price and Payment Information.
Compensation to Engineer A. City agrees to pay to Engineer for all services outlined in Section III, a base design fee in an amount not to exceed $254,160.00. The following services are not included in this base fee:
Compensation for Damages 4.1 If the Principal has disqualified the Bidder from the tender process prior to the award according to Section 3, the Principal is entitled to demand and recover the damages equivalent Xxxxxxx Money Deposit/Bid Security.
Director Compensation Petitioner shall not compensate members of the Charter School’s Governing Board in excess of reasonable expenses incurred in connection with actual attendance at board meetings or with performance of duties associated therewith.
Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -
Compensation in relation to breach In relation to any breach of this contract, the party in breach shall indemnify the Innocent Party against all Relevant Losses.
Compensation for Losses Upon demand of any Lender (with a copy to the Administrative Agent) from time to time, the Borrower shall promptly compensate such Lender for and hold such Lender harmless from any loss, cost or expense incurred by it as a result of:
Compensation for Damages or Losses When investments by investors of either Contracting Party suffer damages or losses owing to war, armed conflict, a state of national emergency, revolt, insurrection, riot or other similar events in the territory of the other Contracting Party, they shall be accorded by the latter Contracting Party a treatment, as regards compensation or other settlement, not less favourable than that accorded to its own investors or to investors of any Third State.
Basic Compensation (a) SALARY. Executive will be paid an annual base salary of $115,000.00, subject to adjustment as provided below (the "Salary"), which will be payable in equal periodic installments according to Employer's customary payroll practices, but no less frequently than monthly. The Salary will be reviewed by the Board of Directors not less frequently than annually, and shall be increased on each anniversary of the Effective Date during the term hereof by an amount equal to not less than ten percent (10%) of the prior year's base salary.
Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.
