Claims for Delay Sample Clauses

Claims for Delay. (General Laws, Chapter 30, Section 390 as added by Chapter 116 of the Acts of 1973) Every contract subject to the provisions of section thirty-nine M of this chapter or subject to section forty-four A of chapter one hundred forty-nine shall contain the following provisions (a) and (b) in their entirety and, in the event a suspension, delay, interruption or failure to act of the awarding authority increases the cost of performance to any subcontractor, that subcontractor shall have the same rights against the general contractor for payment for an increase in the cost of his performance as provisions (a) and (b) give the general contractor against the awarding authority, but nothing in provisions (a) and (b) shall in any way change, modify or alter any other rights which the general contractor or the subcontractor may have against each other.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Claims for Delay. Where the Contractor deems that additional compensation or a time extension is due on account of delay, differing site conditions, breach of Contract, or any other cause other than for work or materials not expressly provided for in the Contract (Extra Work) or which is by written directive of the Engineer expressly ordered by the Engineer , the Contractor shall submit a written notice of intent to the Engineer within ten days after commencement of a delay to a controlling work item expressly notifying the Engineer that the Contractor intends to seek additional compensation, and if seeking a time extension, the Contractor shall also submit a preliminary request for time extension pursuant to 8-7.3.2 within ten calendar days after commencement of a delay to a controlling work item, as to such delay and providing a reasonably complete description as to the cause and nature of the delay and the possible impacts to the Contractor’s work by such delay, and a request for Contract Time extension pursuant to 8-7.3.2 within thirty calendar days after the elimination of the delay. On projects with an original Contract amount of $3,000,000 or less within 90 calendar days after final acceptance of the project in accordance with 5-11, and on projects with an original Contract amount greater than $3,000,000 within 180 calendar days after final acceptance of the project in accordance with 5-11, the Contractor shall submit full and complete documentation as described in 5-12.3 and duly certified pursuant to 5-12.9. If the Contractor fails to submit a certificate of claim as described in 5-12.9, the Department will so notify the Contractor in writing. The Contractor shall have ten calendar days from receipt of the notice to resubmit the claim documentation, without change, with a certificate of claim as described in 5-12.9, without regard to whether the resubmission is within the applicable 90 or 180 calendar day deadline for submission of full and complete claim documentation. Failure by the Contractor to comply with the ten calendar day notice shall constitute a waiver of the claim. There shall be no Contractor entitlement to any monetary compensation or time extension for any delays or delay impacts, whatsoever, that are not to a controlling work item, and then as to any such delay to a controlling work item entitlement to any monetary compensation or time extension shall only be to the extent such is otherwise provided for expressly under 5-12,
Sample 1Sample 2Sample 3See All (4)
Claims for Delay. (General Laws, Chapter 30, Section 390 as added by Chapter 116 of the Acts of 1973)
Sample 1Sample 2Sample 3
Claims for Delay. (a) If Supplier wishes to request an extension in the delivery date for Products provided in a Purchase Order, written request shall be given to Qwest at the time the delay begins, or within (***) thereafter if the resulting delay was not reasonably foreseeable. The request shall state the circumstances of the occurrence, the justification for the delay and extension of time, and the estimated duration of the delay and extension requested. Supplier shall also be obligated to do all in its power to mitigate the adverse impact of such delay at no additional cost to Qwest.
Sample 1Sample 2
Claims for Delay. Should AASDI‘s performance, in whole or in part, be delayed, disrupted, accelerated or suspended in the commencement, prosecution or completion of the Services (“Delay”), as a result of the action or inaction of ASD or inaction of any person or entity other than Client, AASDI’s sole remedy against ASD for shall be a reasonable extension of the time for performance in which to complete the SOW and such remedy will be available only to the extent the Delay was not attributable to AASDI’s fault or negligence. For Claims related to a Delay caused by Client’s action or inaction, and solely only to the extent the Delay was not attributable to AASDI’s fault or negligence, AASDI’s sole remedies against ASD shall be: (a) a reasonable extension of the time for performance in which to complete the Services, provided, however that such extension will be available only to the extent that a similar extension of time has been granted to ASD by Client; and (b) to the extent that Client pays amounts to ASD as compensation for the Delay, AASDI shall receive reasonable compensation for such Delay, not to exceed the amount actually received from Client. AASDI shall only be entitled to the remedies specified in this Section 12.2 if AASDI provides ASD written notification of the Delay and cause of Delay within seventy-two (72) hours of the event causing the Delay.
Sample 1Sample 2
Claims for Delay. (Not included) 5-12.3 Content of Written Claim: As a condition precedent to the Contractor being entitled to additional compensation or a time extension under the Contract, for any claim, the Contractor shall submit a certified written claim to the Department which will include for each individual claim, at a minimum, the following information:
Sample 1Sample 2
Claims for Delay. Subcontractor shall not be entitled to make a claim and shall not make a claim for damages for delay in the performance of its Work occasioned by any act or failure to act of NRC or on account of any adjustment in Subcontractor’s schedule or the Project Schedule more generally. Subcontractor’s sole remedy for any delay shall be a claim for an extension of time to its period of contract performance, and only to the extent that NRC receives such an extension from Owner. If Subcontractor is delayed in the performance of its Work by extraordinary weather conditions or any labor strikes, riots, war, acts of god, or government authorities for reasons other than any act or omission of Subcontractor, Subcontractor may claim an extension of time to complete performance of its Work as provided for herein to the extent that NRC receives such an extension from Owner. Any such request for an extension of time shall be made in accordance with the following paragraph. If Subcontractor believes that any order, directive, condition or circumstance, other than as provided for in this Agreement relating to claims for delay, entitles Subcontractor to an extension of time, Subcontractor shall give to NRC written notice of claim not later than three (3) business days after the occurrence or discovery of the event, condition or circumstance giving rise to the claim and shall, as soon as practicable, furnish sufficient facts in support of Subcontractor’s position as may be necessary for a decision. Any claim by Subcontractor for extra time not so made shall be waived and Subcontractor shall not be entitled to any extension of time as a result thereof. Subcontractor shall be liable to NRC for all liquidated damages or other payments which NRC is obligated to pay Owner on account of delay caused by Subcontractor (“Late Payments”). Subcontractor shall also be liable to NRC for all other costs, expenses or damages (including attorneys’ fees, penalties, and liquidated damages, including the costs for time expended by in-house counsel and other experts) incurred by NRC as a result of a delay by Subcontractor in the performance of its Work herein.
Sample 1
AutoNDA by SimpleDocs
Claims for Delay. The environmental consultant may be left in an anomalous situation in the event that the remedial or abatement contractor's agreement with the owner contains a "no damage for delay" clause. It may well be that the contractor, who is barred from suit against the owner, may wish to xxx the consultant for damages for delay. To guard against this inequity, the owner should be willing to provide the consultant with indemnity coverage against any third-party claims for delay. Recent case law, which establishes this contractor right of action against design professionals, highlights the importance of this protection. As between the consultant and the owner, if the fee arrangement is on a lump-sum basis, it is important that the consultant be given the right to additional compensation if the owner delays or makes the consultant’s performance more difficult or expensive. The "no damage for delay" clause is not appropriately placed in the owner-consultant agreement.
Sample 1

Related to Claims for Delay

  • Claims for Benefits All Claims for benefits will be deemed to have been filed on the date received by AvMed. If a Claim is a Pre-Service or Urgent Care Claim, a Health Professional with knowledge of the Member’s Condition will be permitted to act as the Member’s authorized representative, and will be notified of all approvals on the Member’s behalf.

  • Claims Procedure An Executive or Beneficiary (“claimant”) who has not received benefits under this Agreement that he or she believes should be distributed shall make a claim for such benefits as follows:

  • Claims Procedures Each Party entitled to be indemnified by the other Party (an “Indemnified Party”) pursuant to Section 8.1 or 8.2 hereof shall give notice to the other Party (an “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of any threatened or asserted claim as to which indemnity may be sought, and shall permit the Indemnifying Party to assume the defense of any such claim or any litigation resulting therefrom; provided:

  • Claims and Review Procedure In the event that any claim for benefits that must initially be submitted in writing to the Board of Directors, is denied (in whole or in part) hereunder, the claimant shall receive from First Charter a notice of denial in writing within 60 days, written in a manner calculated to be understood by the claimant, setting forth the specific reasons for denial, with specific reference to pertinent provisions of this Supplemental Agreement. Any disagreements about such interpretations and construction shall be submitted to an arbitrator subject to the rules and procedures established by the American Arbitration Association. The arbitrator shall be acceptable to both First Charter and the Executive (or Beneficiary); if the parties cannot agree on a single arbitrator, the disagreement shall be heard by a panel of three arbitrators, with each party to appoint one arbitrator and the third to be chosen by the other two. No member of the Board of Directors shall be liable to any person for any action taken under Article VIII except those actions undertaken with lack of good faith.

  • Review Procedure If the Plan Administrator denies part or all of the claim, the claimant shall have the opportunity for a full and fair review by the Plan Administrator of the denial, as follows:

  • Notice of Special Matters The Corporation covenants with the Warrant Agent that, so long as any Warrant remains outstanding, it will give notice to the Warrant Agent and to the Registered Warrantholders of its intention to fix a record date that is prior to the Expiry Date for any matter for which an adjustment may be required pursuant to Section 4.1. Such notice shall specify the particulars of such event and the record date for such event, provided that the Corporation shall only be required to specify in the notice such particulars of the event as shall have been fixed and determined on the date on which the notice is given. The notice shall be given in each case not less than 14 days prior to such applicable record date. If notice has been given and the adjustment is not then determinable, the Corporation shall promptly, after the adjustment is determinable, file with the Warrant Agent a computation of the adjustment and give notice to the Registered Warrantholders of such adjustment computation.

  • Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.

  • No Actions, Claims, Etc As of the date hereof, each of the Credit Parties hereby acknowledges and confirms that it has no knowledge of any actions, causes of action, claims, demands, damages and liabilities of whatever kind or nature, in law or in equity, against the Administrative Agent, the Lenders, or the Administrative Agent’s or the Lenders’ respective officers, employees, representatives, agents, counsel or directors arising from any action by such Persons, or failure of such Persons to act under the Credit Agreement on or prior to the date hereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!