Claims and Appeals. The Contractor shall address claims for additional time or compensation under the Contract in writing to the Buyer and Project Manager within ten (10) Days of the date in which the Contractor knows or should know of the basis for the claim. Claims shall be accompanied by supporting documentation and citation to applicable provisions in the Contract documents. The County reserves the right to request additional documentation necessary to adequately review the claim. No claim by the Contractor shall be allowed if asserted after final payment under this Contract. The Buyer and Project Manager shall ordinarily respond to the Contractor in writing with a decision issued jointly, but absent such written response, the claim shall be deemed denied upon the tenth (10th) Day following receipt by the Buyer and Project Manager of the claim, or requested additional documentation, whichever is later. In the event the Contractor disagrees with the determination of the Buyer and Project Manager, the Contractor shall, within five (5) Days of the date of such determination, appeal the determination in writing to the Procurement and Payables Section Manager. Such written notice of appeal shall include all information necessary to substantiate the appeal. The Procurement and Payables Section Manager shall review the appeal and make a determination in writing, which shall be final. Appeal to the Procurement and Payables Section Manager on claims for additional time or compensation shall be a condition precedent to litigation. At all times, the Contractor shall proceed diligently with the performance of the Contract and in accordance with the direction of the Buyer or Project Manager. Failure to comply precisely with the time deadlines under this Section 8.1 as to any claim and appeal shall operate as a waiver and release of that claim and appeal and an acknowledgment of prejudice to the County.
Claims and Appeals. In the event of further developments, the UIPC may reconsider the VCR’s decision to retain intellectual property.
Claims and Appeals. 14 Initial Claims.............................................................................................................................. 14 Appeals....................................................................................................................................... 15 Other Rules and Rights Regarding Claims and Appeals............................................................ 16
Claims and Appeals. The Plan has specific procedures for making a claim for additional benefits. This claim and appeal process must be exhausted before you can file a lawsuit in court. The claim and appeal process has two levels: the initial claim and review on appeal. They operate as follows: Initial Claims
Claims and Appeals. A. Delta Dental will adjudicate and process all clean Claims submitted for Contractor’s Dental Plan, in accordance with this Contract, the Certificate and Delta Dental’s standard operating procedures.
Claims and Appeals. 43 Section 1 Claims Procedure 43 Section 2 Claim Denial. 44 Section 3 Claim Appeals 44 Section 4 Arbitration. 46
Claims and Appeals. The Seller will, upon the request of the Buyer, submit an appropriate claim to the Government, obtain a contracting officer decision or prosecute an appeal of any contracting officer decision with respect to any action taken or not taken by the Government under the Contract that in any way reduces or delays the payment of any Contract Payment or that, in the reasonable opinion of the Buyer, could adversely affect the Contract Payments.
Claims and Appeals. The Organization shall have the right to lodge a complaint on proceeding of the process defined in § 1 including the right to lodge a complaint regarding work of auditors. Complaints shall be lodged according to the procedure provided on the website xxx.xxxx.xxx.xx. The Organization shall have the right to submit an appeal against a decision of the PCBC. Appeals shall be lodged according to the procedure provided on the website xxx.xxxx.xxx.xx. The principle of impartiality and confidentiality shall be observed at all stages of proceeding in processing complaints/appeals.
Claims and Appeals. If any part of an application for benefits under the Plan is denied, the following claim procedure applies: (a) The Administrator(s) shall act upon each application for benefits within ninety (90) days after receipt of the application. If special circumstances require an extension of time, such Administrator(s) shall notify the applicant of the delay and shall act within one hundred eighty (180) days after receipt of the application. The Administrator(s) shall also explain the reason for the delay and indicate the date on which a decision may be expected. If the Administrator(s) does not act on an application for benefits within ninety (90) days (or one hundred eighty (180) days, if applicable), the application will be deemed to have been denied. (b) If a claim is denied in whole or in part, the applicant shall be notified in writing of the following information: (1) the specific reasons for such denial; (2) specific reference to pertinent Plan provisions on which the denial is based; (3) a description of any additional material or information necessary for the claimant to perfect the claim and an explanation of why such material or information is necessary; and (4) an explanation of the Plan's claim review procedure. (c) The applicant may appeal by delivering a written notice to the Administrator(s) within sixty (60) days after receiving notice of denial from the Administrator(s) or, if no notice of denial was received, within one hundred fifty (150) days (or two hundred forty (240) days, if applicable) after the claim was filed. The applicant's notice of appeal should: (1) request a review of his application for benefits by the Administrator(s); (2) set forth all of the grounds upon which his request for review is based and any facts in support; and (3) set forth any issues or comments which the applicant deems pertinent to his application. If he appeals, the applicant may review pertinent documents at any reasonable time and place specified by the Administrator(s) and may submit any additional written materials pertinent to the appeal not set forth in the notice of appeal. (d) Any appeal will be reviewed by the Administrator(s). The applicant, who may be represented by any person, will be entitled to appear before the Administrator(s) to present his claim. The Administrator(s) will decide the appeal not later than sixty (60) days after receiving the notice of appeal. If special circumstances require an extension of time, a decision will be made as soon ...
Claims and Appeals. In the event a Participant or Beneficiary believes he or she is entitled to a payment from the Company which has not been made, he or she may submit a claim for benefits to the Administrative Committee. Any denial of the claim shall be made by the Administrative Committee in writing and shall specify the Plan provisions upon which the denial is based and any additional information or documentation which the Participant would need to submit to perfect his or her claim. The Participant may appeal in writing to the Administrative Committee any denial of his or her claim within 90 days following the denial, and shall include any additional information or documentation helpful to support his or her claim. The Administrative Committee's decision shall be made in writing within 90 days of receipt of the appeal and shall be final and binding on the Participant and the Company.
