CHANGES TO THE CONTRACT DOCUMENTS Sample Clauses

CHANGES TO THE CONTRACT DOCUMENTS. The Design Professional shall incorporate changes (issued as revision drawings with Field Orders, RFIs or Change Orders) into the Record Documents on a monthly basis during the Construction phase.
Sample 1Sample 2
CHANGES TO THE CONTRACT DOCUMENTS. 2.9.1 Master Architect shall prepare drawings and specifications needed by University Representative to issue Field Orders and Change Orders for University’s approval and execution.
Sample 1Sample 2
CHANGES TO THE CONTRACT DOCUMENTS. 4.1 The Contract Time shall be reasonably extended for any delays caused by the Owner’s failure to complete finish selections according to the dates set in the Material Ordering Decision Date Schedule. Additionally, if Contractor is delayed at any time in the progress of the Work by changes to the Scope of Work, by labor disputes, fire, unusual delay in deliveries, abnormal adverse weather conditions, unavoidable casualties, lack of timely payment by Owner, any causes beyond Contractor's control, or by other claims which may justify delay, then the Contract Time shall be reasonably extended.
Sample 1Sample 2
CHANGES TO THE CONTRACT DOCUMENTS. The Awarding Authority may require changes in the scope of services to be performed or provided by the Contractor. All such changes, which are mutually agreed upon by and between the parties, shall be incorporated in written amendments to the contract, which may also be in the form of letter agreements. All such amendments or supplemental agreements shall state any increase or decrease in the amount of compensation due the Contractor for any change in the scope of services and/or schedule. All alterations or additions, material or otherwise, to the terms and conditions of this Contract must be in writing, be signed by the Official and the Contractor. Any waiver, expressed or implied, by the Awarding Authority or the Official of any rights, terms, or conditions of this Contract shall not operate to waive such rights, terms, or conditions or any other rights, terms or conditions, beyond the specific instance of waiver. Unless all the terms and conditions for the delivery or provision of services by the Contractor to the Awarding Authority specified by this Contract are expressly set forth in a writing, incorporated herein by reference, such provision of services shall require written approval of, or direction by the Official, prior to the incurrence of any liability by the Awarding Authority.
Sample 1

Related to CHANGES TO THE CONTRACT DOCUMENTS

  • Changes to the Contract Changes can be made to the contract in any of the following ways:

  • THE CONTRACT DOCUMENTS The Contract Documents consist of the State-Contractor Agreement, the Conditions of the Contract (General, Supplementary and other Conditions), the Drawings, the Specifications, and all Addenda issued prior to bid opening and any Change Orders after execution of the Contract.

  • Contract Documents The contract documents shall consist of the following:

  • Copies of Contract Documents to Contractor Without charge to the Contractor the Design Professional shall furnish to the Contractor up to five sets of completed Contract Documents in hardcopy, one set of reproducible and electronic background floor and reflected ceiling plan drawings and, if requested, one copy in read-only electronic format. The Contractor may obtain such additional sets of Contract Documents, as the Contractor deems necessary and shall pay the cost of reproduction of such additional sets to the Design Professional.

  • PARTIES TO THE CONTRACT This Contract is solely between the Company and the SBA which administers the FHCF. In no instance shall any insured of the Company or any claimant against an insured of the Company, or any other third party, have any rights under this Contract, except as provided in Article XIV. The SBA will only disburse funds to the Company, except as provided for in Article XIV of this Contract. The Company shall not, without the prior approval of the Office of Insurance Regulation, sell, assign, or transfer to any third party, in return for a fee or other consideration any sums the FHCF pays under this Contract or the right to receive such sums.

  • CONTRACTOR’S SUBMISSION OF CONTRACT MODIFICATIONS In connection with any Contract modification, OGS reserves the right to:  request additional information  reject Contract modifications  remove Products from Contract modification requests  request additional discounts for new or existing Products

  • OGS Contract Documents This Centralized Contract is composed of the following documents:  The Contract (that portion preceding the signatures)  Appendix A - Standard Clauses for New York State Contracts (January 2014)  Appendix B - General Specifications January 2015 22772 Project Based Information Technology Consulting (Statewide)  Appendix C - Contract Modification Procedure  Appendix D – Pricing Schedule  Appendix E – Report of Contract Purchases  Appendix F – Project Based Information Technology Consulting Services Processes and Forms o Attachment 1- Mini-Bid Template o Attachment 2- How to Use This Contract o Attachment 3- Enhancement Request Template o Attachment 4- No Cost Change Request Template o Attachment 5- Mini-Bid Participation Interest Template  Appendix G – Contractor and OGS Information

  • Changes to the Work 7.1 Changes to the Work may be accomplished by preparation of and execution of a change order or construction change directive. Change orders or construction change directives will be preceded by a change proposal request initiated by the Architect. The Construction Manager shall provide prices and details within 30 days of receipt of a change proposal request, and the Architect shall forward the completed change proposal request to the Owner within 15 days after receipt of the information provided by the Construction Manager.

  • AMENDMENTS TO THE CONTRACT The Contract shall be amended as follows:

  • Construction Contract Documents The Construction Contract Documents shall consist of the plans and specifications prepared by the Engineer, and any addenda and change orders thereto, and the Owner-Contractor Agreement, all of which shall be compatible and consistent with this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.