Changes or Cancellations Sample Clauses

Changes or Cancellations. The Counties may change or cancel items of Equipment and Software prior to shipment. If the Counties issue a Change Request or other mutually agreed upon form causing a delivery delay or cancels an order less than 20 Days prior to scheduled shipment, the Counties may be subject to a restocking charge, provided that imposing such charges is part of Contractor’s existing policies. Such charges would be equal to Contractor’s actual costs of restocking, which shall in any case be no greater than five percent of the Charges for the Equipment being delayed or cancelled.
Sample 1Sample 2
AutoNDA by SimpleDocs
Changes or Cancellations. AOC may change or cancel items of Equipment and Software prior to shipment. If AOC issues a Change Order or other mutually agreed upon form causing a delivery delay or cancels an order less than 20 Days prior to scheduled shipment, AOC may be subject to a restocking charge, provided that imposing such charges is part of Contractor’s existing policies. Such charges would be equal to Contractor’s actual costs of restocking, which shall in any case be no greater than five percent of the Charges for the Equipment being delayed or cancelled.
Sample 1Sample 2
Changes or Cancellations. A request may be changed or cancelled fifteen (15) calendar days prior to the requested date of use. For all changes or cancellations, applicants must contact Facilities Scheduling Office at 000-000-0000
Sample 1Sample 2
Changes or Cancellations. 5.1 Only the registered trainer xxxxxx will be able to change or cancel a booking. Changes or cancellations can be made on the website, which is accessible 24 hours a day. If you need to contact us by phone, this must be done during office hours. Candidates named on a booking will not be able to change or cancel that booking.
Sample 1
Changes or Cancellations. 3.1 If the Client modifies the work for which services are being commissioned after formation of the contract, then Xxxxx Publications is entitled to adjust the lead time and/or fee, or reject the work. Any services already rendered for this work will be assessed in mutual consultation and in accordance with the principles of reasonableness and fairness.
Sample 1
Changes or Cancellations. The CalSAWS Consortium may change or cancel items of Equipment and Software prior to shipment. If the CalSAWS Consortium issue a Change Request or other mutually agreed upon form causing a delivery delay or cancels an order less than 20 Days prior to scheduled shipment, the CalSAWS Consortium may be subject to a restocking charge, provided that imposing such charges is part of Contractor’s existing policies. Such charges would be equal to Contractor’s actual costs of restocking, which shall in any case be no greater than five percent of the Charges for the Equipment being delayed or cancelled.
Sample 1
Changes or Cancellations. If the Customer cancels or alters an Experience after making a Booking, all communications with the Customer will be facilitated by and through thl.
Sample 1
AutoNDA by SimpleDocs
Changes or Cancellations. State may change or cancel items of Equipment and Software prior to shipment. If State issues a Change Order or other mutually agreed upon form causing a delivery delay or cancels an order less than 20 Days prior to scheduled shipment, State may be subject to a restocking charge, provided that imposing such charges is part of Contractor’s existing policies. Such charges would be equal to Contractor’s actual costs of restocking, which shall in any case be no greater than five percent of the Charges for the Equipment being delayed or cancelled.
Sample 1
Changes or Cancellations. Costs incurred due to changes or cancellation of an order will be charged to the Buyer.
Sample 1

Related to Changes or Cancellations

  • Changes and Cancellations Order changes or cancellations are subject to Seller’s written approval and additional charges may apply. Seller shall not be liable for any delays due to order changes. Seller may make changes in the Products without obligation to install such changes in any Product manufactured prior thereto. Seller may make such changes to any ordered Products as do not, in Seller’s judgment, interfere with the satisfactory operation of the Product. Seller may charge Buyer a cancellation charge of twenty percent (20%) if Buyer cancels any part of an order or if Seller terminates an order due to Buyer's violation of any duty to Seller.

  • Absence of Certain Changes or Events Except as set forth in Section 3.1(m) of the Company Disclosure Schedule, since December 31, 2005 (i) there has not been any change, or, to the knowledge of Company, any event involving a prospective change, in the business, financial condition or results of operations or, to the knowledge of Company, prospects of Company or any of its Subsidiaries or in the relationship of Company or its Subsidiaries with respect to their employees, creditors, suppliers, distributors, customers or others with whom they have business relationships, which has had, or would be reasonably likely to have, a Material Adverse Effect on Company, (ii) Company and each of its Subsidiaries have conducted their respective businesses in the ordinary course consistent with their past practices and neither Company nor any of its Subsidiaries has taken any action or entered into any transaction, and, to the knowledge of Company, no event has occurred, that would have required Commerce or Sub's consent pursuant to Section 4.1 of this Agreement if such action had been taken, transaction entered into or event had occurred, in each case, after the date of this Agreement, nor has Company or any of its Subsidiaries entered into any agreement, plan or arrangement to do any of the foregoing, (iii) there have been no dividends or other distributions declared, set aside or paid in respect of Company Common Stock, nor has any action with respect to Company Common Stock proscribed by Section 4.1 of this Agreement occurred or been taken, and (iv) Company and its Subsidiaries have not entered into any employment contract with any director, officer or salaried employee, paid any or made any accrual or arrangement for payment of bonuses or special compensation of any kind or any severance or termination pay to any of their officers, employees or directors, increased the rate of compensation, if any, or instituted or made any material increases in any officer's, employee's or director's welfare, retirement or similar plan or arrangement, other than annual and merit increases made in accordance with past practices and procedures.

  • Coverage Changes and Effective Dates 133133 1 Section 6. Basic Coverages. 141141 2 Section 7. Optional Coverages. 163162

  • Changes Due to a Life Event After the initial enrollment period and outside of any open enrollment period, an employee may elect to change health or dental coverage (including adding or canceling coverage) and any applicable employee contributions in the following situations (as long as allowed under the applicable provisions, regulations, and rules of the federal and state law in effect at the beginning of the plan year). The request to change coverage must be consistent with a change in status that qualifies as a life event, and does not include changing health or dental plans, which may only be done under the terms of Section 5A above. Any election to add coverage must be made within thirty (30) days following the event, and any election to cancel coverage must be made within sixty (60) days following the event. (An employee and a retired employee may add dependent health or dental coverage following the birth of a child or dependent grandchild, or following the adoption of a child, without regard to the thirty (30) day limit.) These life events (for both employees and retirees) are:

  • Amendments, Changes and Modifications Except as to the termination rights of both Parties as indicated in the Facilities Lease, this Site Lease may not be amended, changed, modified, altered or terminated without the written agreement of both Parties hereto.

  • Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract.‌ If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.

Time is Money Join Law Insider Premium to draft better contracts faster.