Changes in This Policy. We may unilaterally change this Policy upon renewal, if We give You 45 days’ prior written notice.
Changes in This Policy Sample Clauses
Related to Changes in This Policy
Charges in This Case 2. The superseding indictment in this case charges defendant with wire fraud, in violation of Title 18, United States Code, Section 1343.
Changes in the Work The Department may order changes in the work, the Contract Amount being adjusted accordingly. Any monetary adjustment or any substantive change in the work shall be in the form of an amendment, signed by both parties and approved by the State Purchases Review Committee. Said amendment must be effective prior to execution of the work.
Changes in the Law Any alterations, additions, or deletions to the terms of this Agreement which are required by changes in federal or state law are automatically incorporated into this Agreement without written amendment to the Agreement and shall be effective on the date designated by said federal or state law.
Changes in Writing Other than in connection with the addition of additional Subsidiaries, which become parties hereto by executing a supplement hereto in the form attached as Annex I, neither this Guaranty nor any provision hereof may be changed, waived, discharged or terminated orally, but only in writing signed by each of the Guarantors and the Administrative Agent.
MINOR CHANGES IN THE WORK 7.4.1 The Architect will have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the Owner and Contractor. The Contractor shall carry out such written orders without delay.
Changes in Agreement Any changes deemed necessary in this Agreement may be made by mutual agreement at any time during the existence of this Agreement.
Changes in Contract Time All Change Orders must state that the Contract Time and the Material Completion and Occupancy Date either are not changed or are increased or decreased by a specific number of Days. The CONTRACTOR must provide written justification for the extension to the Design Professional and to the Owner. The written justification must demonstrate an anticipated actual increase in the time required to complete the Work beyond that allowed by the Contract as adjusted by prior Change Orders to the Contract. No extension to the Contract Time shall be allowed unless the additional or changed Work increases the length of the critical path beyond the Material Completion and Occupancy Date. If approved, the increase in time required to complete the Work shall be added to the Contract Time. The Owner may decrease, by Change Order, the Contract Time when an Owner-requested deletion from the Work results in a decrease in the actual time required to complete the Work as demonstrable on the critical path of the Construction Progress Schedule. Eligibility and processing requirements for Time Dependent Overhead Costs for compensable delay is addressed in Article 3.3.8 and 3.3.10.
In this Agreement 7.1.6 Any external loan, security, compensation, covenant or other compensation liabilities of the Pledgor’s (1) is required to be repaid or performed prior to the due date due to default; or (2) is due but cannot be repaid or performed as scheduled and thereby cause the Pledgee to deem that the Pledgor’s capacity to perform the obligations herein is affected.
Modifications to this Agreement This Agreement constitutes the entire understanding of the parties on the subjects covered. Employee expressly warrants that he or she is not accepting this Agreement in reliance on any promises, representations, or inducements other than those contained herein. Modifications to this Agreement or the Plan can be made only in an express written contract executed by a duly authorized officer of the Company.
CHANGES IN CONTRACT 5.1 The Purchaser shall have the right at any time to make changes in the design and/or the specifications of any or all of the Products or part thereof, delivery terms, scope or other provisions of the Contract, by means of a written notice to the Supplier. If in the Supplier’s reasonable opinion such changes affect the cost or time required for performance of the Goods and Services or any other provision(s) of the Contract, the Supplier shall notify the Purchaser promptly in writing, but in no event later than ten (10) days after the receipt of the Purchaser’s notice, including appropriate substantiation regarding the claimed impact of the change. Subject to the Supplier’s notification in accordance with the foregoing, if and to the extent that the changes requested by the Purchaser reasonably justify in the circumstances an adjustment of the price, delivery schedule and/or other provision of the Contract, then an equitable adjustment will be made by the Purchaser (“Change Order”). The Purchaser has the right to instruct the Supplier to commence the changes prior to having finalised the adjustment to the Change Order. In the absence of a notification by the Supplier in accordancewith this Article5.1, the Supplier shall be deemed tohavewaived its rights for an adjustment and shall carry out the change, and the Purchaser shall be entitled to assume that such changewill nothave any impacton anymaterial term of the Contract, including time schedule, warranties and price.
