Changes in Scheduling Sample Clauses

Changes in Scheduling. (a) In situations, other than emergencies, the scheduled employees are entitled to forty-eight (48) hours' notice of changes in their respective work schedules. In emergency situations beyond the Employer's control, as in the case of the failure of an employee to report for an assigned shift, the Employer may give less than forty-eight (48) hours' notice.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Changes in Scheduling. (a) In situations, other than emergencies, the scheduled employees are entitled to five (5) calendar days’ notice of changes in their respective work schedules.
Sample 1
Changes in Scheduling. (a) Employees who are unable to report for their scheduled shift due to personal illness or emergency will provide the Employer with notice at the earliest possible time to allow the Employer to cover the absence.
Sample 1
Changes in Scheduling. ‌ In situations, other than emergencies, the scheduled employees are entitled to seven calendar days' notice of changes in their respective work schedules. In emergency situations beyond the Employer's control, as in the case of the failure of an employee to report for an assigned shift, the Employer may give less than 48 hours' notice. Employees who are unable to report for their scheduled shift due to personal illness or emergency, shall provide the Employer with notice at the earliest possible time to allow the Employer to cover the absence. Where the Employer changes an employee's schedule without seven calendar days' notice, the employee is entitled to overtime rates. Employees may exchange shifts with the prior written authorization of the Employer, provided that a minimum of 48 hours of notice is given. There shall be no increased cost to the Employer as a result of a shift exchange. This provision is not intended to be used for extensive and/or ongoing shift exchanges between employees. Where an employee reports for work as scheduled and no work is available such employee will be entitled to a minimum of four hours' pay at the employee's regular rate of pay provided that, if requested by the Employer, the employee shall perform a minimum of four hours of such available work as the Employer may assign. Where the Employer changes an employee's schedule, the employee(s) where there is disagreement, must make every effort to settle the dispute with the Employer. If the employee(s) cannot reach agreement to a change to the existing work schedules, the employee(s) and union xxxxxxx shall provide the Employer with earliest possible advance notice in writing; The Employer shall have 14 days from the date notice is given to reach agreement with the employee(s) on work schedules; If the parties are unable to reach agreement within 14 days either party may refer the matter to an arbitrator.
Sample 1
Changes in Scheduling. ‌ In situations other than emergencies, the scheduled employees are entitled to forty-eight (48) hours' notice of any change in their respective work schedules. In emergency situations which are beyond the Employer's control, as in the case of the failure of an employee to report for an assigned schedule, the Employer may give notice of less than forty-eight (48) hours. Employees who become aware that they are not going to be able to report for work as scheduled, are obligated to provide the Employer with notice at the earliest possible time, or to have someone else notify the Employer on their behalf, to allow the Employer time to cover the absence. Employees whose schedules are changed without the advance notice specified, cannot be disciplined if they advise the Employer that they cannot comply with the changed starting and finishing times for the first shift of the new schedule. Employees who report to work as scheduled shall be paid for the shift in the event that the shift is cancelled. Employees may exchange shifts with the prior authorization of the Employer provided that a minimum advance notice of forty-eight (48) hours is given and the Employer shall not unreasonably withhold such authorization. There shall be no increased cost to the Employer should employees exchange shifts with prior notification to the Employer and once the Employer has authorized the exchange of shifts there shall be no grievances filed as a result of an authorized and agreed to shift exchange.
Sample 1

Related to Changes in Scheduling

  • CHANGES IN SCOPE Any changes in the scope of the Services to be performed under this Contract shall be in the form of a written amendment to this Contract, mutually agreed to and signed by both parties, specifying any such changes, fee adjustments, any adjustment in time of performance, or any other significant factors arising from the changes in the scope of Services.

  • CHANGES IN SCOPE OF SERVICES Only the Xxxxxx County Board of Supervisors has the authority to agree to any extension of time, change order, change in the scope of work, change in the contract price, or other term or condition affecting either Contractor's or County's duties set forth herein. Adjustments in compensation, if any, shall be determined through negotiation between the parties to the Agreement and are subject to approval by the Board of Supervisors. Contractor acknowledges that no County staff person or County officer other than the Board of Supervisors has the power to amend the terms and conditions of this Agreement. Any change not so authorized in advance in writing by the Board of Supervisors shall be null and void.

  • Changes in Work A. Work Previously Submitted as Satisfactory. If the Engineer has submitted work in accordance with the terms of this contract but the State requests changes to the completed work or parts thereof which involve changes to the original scope of services or character of work under the contract, the Engineer shall make such revisions as requested and as directed by the State. This will be considered as additional work and paid for as specified under Article 4, Additional Work.

  • Changes in Work Schedules (a) In situations other than emergencies, the scheduled employees are entitled to forty-eight (48) hours notice of any change in their respective work schedules.

  • Changes in Service This Agreement is made in good faith based upon the present and projected conditions and the quality of the equipment and/or Property, as well as its present ownership and management. Should changes in any of these elements occur which the Judicial Council believes may adversely affect the Program, the Judicial Council reserves the right to renegotiate this Agreement or terminate pursuant to the termination for cause provision, as set forth herein, without penalty or prejudice.

  • Changes in Services The parties agree and acknowledge that any Provider may make changes from time to time in the manner of performing the applicable Services if such Provider is making similar changes in performing similar services for itself, its Affiliates or other third parties, if any, and if such Provider furnishes to the Recipient substantially the same notice (in content and timing) as such Provider provides to its Affiliates or other third parties, if any, respecting such changes. In addition, and without limiting the immediately preceding sentence in any way, and notwithstanding any provision of this Agreement to the contrary, such Provider may make any of the following changes without obtaining the prior consent of the Recipient: (i) changes to the process of performing a particular Service that do not adversely affect the benefits to the Recipient of such Provider’s provision or quality of such Service in any material respect or materially increase the charge for such Service; (ii) emergency changes on a temporary and short-term basis; and (iii) changes to a particular Service in order to comply with applicable Law or regulatory requirements.

  • Changes in Writing Other than in connection with the addition of additional Subsidiaries, which become parties hereto by executing a supplement hereto in the form attached as Annex I, neither this Guaranty nor any provision hereof may be changed, waived, discharged or terminated orally, but only in writing signed by each of the Guarantors and the Administrative Agent.

  • Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.

  • Changes in Contract Time All Change Orders must state that the Contract Time and the Material Completion and Occupancy Date either are not changed or are increased or decreased by a specific number of Days. The CONTRACTOR must provide written justification for the extension to the Design Professional and to the Owner. The written justification must demonstrate an anticipated actual increase in the time required to complete the Work beyond that allowed by the Contract as adjusted by prior Change Orders to the Contract. No extension to the Contract Time shall be allowed unless the additional or changed Work increases the length of the critical path beyond the Material Completion and Occupancy Date. If approved, the increase in time required to complete the Work shall be added to the Contract Time. The Owner may decrease, by Change Order, the Contract Time when an Owner-requested deletion from the Work results in a decrease in the actual time required to complete the Work as demonstrable on the critical path of the Construction Progress Schedule. Eligibility and processing requirements for Time Dependent Overhead Costs for compensable delay is addressed in Article 3.3.8 and 3.3.10.

  • Change in Scope For substantial modifications in authorized Project scope, and/or substantial modifications of drawings and/or specifications previously accepted by City, when requested by City and through no fault of Consulting Engineer/Architect, the Consulting Engineer/Architect shall be compensated for time and expense required to incorporate such modifications at Consulting Engineer/Architect's standard hourly rates per Exhibit B; provided, however, that any increase in contract price or contract time must be approved through a written change order. Consulting Engineer/Architect shall correct or revise any errors or deficiencies in its designs, drawings or specifications without additional compensation when due to Consulting Engineer/Architect's negligence or other actionable fault.

Time is Money Join Law Insider Premium to draft better contracts faster.