Notice of Delay Within Fourteen (14) days after the date of occurrence of any cause of delay, on account of which the BUILDER claims that it is entitled under this Contract to a postponement of the Delivery Date, the BUILDER shall notify the BUYER in writing or by telefax confirmed in writing of the date when such cause of delay occurred. Likewise, within Fourteen (14) days after the date of ending of such cause of delay, the BUILDER shall notify the BUYER in writing or by xxxxxxx confirmed in writing of the date when such cause of delay ended. The BUILDER shall also notify the BUYER of the period, by which the Delivery Date is postponed by reason of such cause of delay, with all reasonable dispatch after it has been determined. If the BUILDER does not give the timely advice as above, the BUILDER shall lose the right to claim such delays as permissible delay. Failure of the BUYER to acknowledge to the BUILDER’s claim for postponement of the Delivery Date within Fourteen (14) days after receipt by the BUYER of such notice of claim shall be deemed to be a waiver by the BUYER of its right to object to such postponement of the Delivery Date.
Notice of Force Majeure Each Party agrees to give the other Party prompt written notice of the occurrence of any Force Majeure Event, the nature thereof, and the extent to which the affected Party will be unable fully to perform its obligations hereunder. Each Party further agrees to use reasonable efforts to correct the Force Majeure Event as quickly as possible and to give the other Party prompt written notice when it is again fully able to perform such obligations.
Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
Notice to Landlord In the event Landlord’s consent is required pursuant to Section 15.1, Tenant shall first notify Landlord of its desire to do so and shall submit in writing to Landlord (the “Transfer Notice”); (i) the size and location of the space Tenant proposes to assign or sublet; (ii) the name of the proposed assignee or subtenant; (iii) the date on which the Tenant proposes that the transfer be effective, which shall not be earlier than the date which is 30 days after the Transfer Notice (iv) the nature of the proposed assignee’s or subtenant’s business to be carried on in the Premises; (v) the terms and provisions of the proposed sublease or assignment; (vi) such reasonable financial information as Landlord may request concerning the proposed assignee or subtenant, and (vii) such other information as Landlord may reasonably require. Tenant agrees to reimburse Landlord for Landlord’s actual costs and attorneys’ fees (not to exceed $5000) incurred in conjunction with the processing and documentation of any such requested assignment, subletting, transfer, change or ownership or hypothecation of this Lease. Notwithstanding the foregoing, within five (5) days after any assignment or sublet of Tenant’s interest in this Lease (including any assignment by operation of law or the transfer of fifty percent (50%) or more of the equity interests in Tenant measured by voting power or share of Tenant’s profit), Tenant shall provide Landlord a written notice of such assignment or sublet, which notice shall include the date on which the transfer occurred and each of the items specified in items (i), (ii), (iv), (v) and (vii) above.
Notice of Direct Claims Any claim for indemnification or contribution under this Agreement or any Ancillary Agreement that does not result from a Third-Party Claim shall be asserted by written notice given by the Indemnitee to the applicable Indemnifying Party; provided, that the failure by an Indemnitee to so assert any such claim shall not prejudice the ability of the Indemnitee to do so at a later time except to the extent (if any) that the Indemnifying Party is prejudiced thereby. Such Indemnifying Party shall have a period of thirty (30) days after the receipt of such notice within which to respond thereto. If such Indemnifying Party does not respond within such thirty (30)-day period, such specified claim shall be conclusively deemed a Liability of the Indemnifying Party under this Section 4.6(b) or, in the case of any written notice in which the amount of the claim (or any portion thereof) is estimated, on such later date when the amount of the claim (or such portion thereof) becomes finally determined. If such Indemnifying Party does not respond within such thirty (30)-day period or rejects such claim in whole or in part, such Indemnitee shall, subject to the provisions of Article VII, be free to pursue such remedies as may be available to such party as contemplated by this Agreement and the Ancillary Agreements, as applicable, without prejudice to its continuing rights to pursue indemnification or contribution hereunder.
Tenant’s Notice If Tenant desires to assign this Amended and Restated Lease or sublet all or any portion of the Premises (sometimes referred to herein as a “Transfer”), Tenant shall give notice thereof to Landlord, which shall be accompanied by (a) with respect to an assignment of this Amended and Restated Lease, the date Tenant desires the assignment to be effective, and (b) with respect to a sublet of all or a part of the Premises, a description of the portion of the Premises to be sublet and the commencement date of such sublease. If Tenant has vacated all or substantially all of the Premises or is in the process of making arrangements to do so (with no intention of returning to the Premises during the Term), and if the proposed transaction is either an assignment of this Amended and Restated Lease, or a sublease of the entire Premises, such notice shall be deemed an offer from Tenant to Landlord of the right, at Landlord’s option, to terminate this Amended and Restated Lease with respect to the entire Premises. If the proposed transaction is a sublease of a portion of the Premises, which, together with all other presently existing subleases, comprises a subletting of more than 1/3rd of the rentable square footage of the Premises, and such sublease is for a term substantially equal to the then remaining Term of this Amended and Restated Lease, such notice shall be deemed an offer from Tenant to Landlord of the right, at Landlord’s option to terminate this Amended and Restated Lease with respect to such space as Tenant then proposes to sublease (the “Partial Space”), but not any other previously subleased space, upon the terms and conditions hereinafter set forth. Such option may be exercised by notice from Landlord to Tenant within 20 days after delivery of Tenant’s notice. If Landlord exercises its option to terminate this Amended and Restated Lease, (a) Tenant shall have the right within 7 days to revoke the request to assign or sublease thereby extinguishing Landlord’s right to terminate this Amended and Restated Lease, or (b) if the Tenant does not give such notice within 7 days, (i) this Amended and Restated Lease shall end and expire with respect to all or a portion of the Premises, as the case may be, on the date that such assignment or sublease was to commence, provided that such date is in no event earlier than 90 days after the date of the above notice unless Landlord agrees to such earlier date, (ii) Rent shall be apportioned, paid or refunded as of such date, (iii) Tenant, upon Landlord’s request, shall enter into an amendment of this Amended and Restated Lease ratifying and confirming such total or partial termination, and setting forth any appropriate modifications to the terms and provisions hereof, and (iv) Landlord shall be free to lease the Premises (or any part thereof) to Tenant’s prospective assignee or subtenant or to any other party. Landlord shall pay all costs to make the Partial Space a self-contained rental unit and to install any required Building corridors.
Legal Action Notice A prompt report of any legal actions pending or threatened in writing against Borrower or any of its Subsidiaries that could result in damages or costs to Borrower or any of its Subsidiaries of, individually or in the aggregate, One Hundred Thousand Dollars ($100,000) or more; and
Events Requiring Notice to the Representative The Company shall use its best efforts to cause the Registration Statement to remain effective with a current prospectus for at least nine (9) months after the Applicable Time, and shall notify the Representative immediately and confirm the notice in writing: (i) of the issuance by the Commission of any stop order or of the initiation, or the threatening, of any proceeding for that purpose; (ii) of the issuance by any state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (iv) of the receipt of any comments or request for any additional information from the Commission; and (v) of the happening of any event during the period described in this Section 3.5 that, in the judgment of the Company, makes any statement of a material fact made in the Registration Statement, the Pricing Disclosure Package or the Prospectus untrue or that requires the making of any changes in (a) the Registration Statement in order to make the statements therein not misleading, or (b) in the Pricing Disclosure Package or the Prospectus in order to make the statements therein, in light of the circumstances under which they were made, not misleading. If the Commission or any state securities commission shall enter a stop order or suspend such qualification at any time, the Company shall make every reasonable effort to obtain promptly the lifting of such order.
Notice to NYSE Parent shall, to the extent possible, give the NYSE not less than ten (10) days’ advance notice of the Record Date in compliance with Rule 10b-17 under the Exchange Act.
Notice of Defects The BUYER or its duly authorised representative will notify the BUILDER in writing or by facsimile promptly after discovery of any defect for which a claim is to be made under this guarantee. The BUYER’s written notice shall include full particulars as to the nature of the defect and the extent of the damage caused thereby, but excluding consequential damage as hereinafter provided. The BUILDER will be under no obligation with respect to this guarantee in respect of any claim for defects discovered prior to the expiry date of the guarantee, unless notice of such defects is received by the BUILDER before the expiry date. However, facsimiled advice received by the BUILDER within seven (7) days after such expiry date that a claim is forthcoming will be sufficient compliance with the requirement as to time, provided that such facsimiled advice shall include at least a brief description of the defect including the identity of the equipment, extent of damage, name and number of any replacement part and description of any remedial work required, and that full particulars are given to the BUILDER not later than fourteen (14) days after the expiry date.
