MINOR CHANGES IN THE WORK 7.4.1 The Architect will have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the Owner and Contractor. The Contractor shall carry out such written orders without delay.
Termination for Changes in Budget or Law The JBE’s payment obligations under this Agreement are subject to annual appropriation and the availability of funds. Expected or actual funding may be withdrawn, reduced, or limited prior to the expiration or other termination of this Agreement. Funding beyond the current appropriation year is conditioned upon appropriation of sufficient funds to support the activities described in this Agreement. The JBE may terminate this Agreement or limit Contractor’s Services (and reduce proportionately Contractor’s fees) upon Notice to Contractor without prejudice to any right or remedy of the JBE if: (i) expected or actual funding to compensate Contractor is withdrawn, reduced or limited; or (ii) the JBE determines that Contractor’s performance under this Agreement has become infeasible due to changes in applicable laws.
Complete Work without Extra Cost Except to the extent otherwise specifically stated in this contract, the Contractor shall obtain and provide, without additional cost to the City, all labor, materials, equipment, transportation, facilities, services, permits, and licenses necessary to perform the Work.
Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract. If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.
Classification Changes When the University determines that a revision of a class specification for positions covered by this agreement is needed, and such revision affects the collective bargaining unit designation, the University shall notify AFSCME in writing of the proposed change. AFSCME shall notify the University, in writing, within fifteen (15) days of receipt of the proposed changes, of any comments it has concerning the proposed changes or of its desire to discuss the proposed changes.
Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Housing.
CONTRACT ITEM CHANGES A. If a manufacturer discontinues a contracted item, that item will automatically be considered deleted from the contract with no penalty to Contractor. However, H-GAC may at its sole discretion elect to make a contract award to the next lowest Respondent for the item, or take any other action deemed by H-GAC, at its sole discretion, to be in the best interests of its Customers.
For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.
Changes in the Work The Department may order changes in the work, the Contract Amount being adjusted accordingly. Any monetary adjustment or any substantive change in the work shall be in the form of an amendment, signed by both parties and approved by the State Purchases Review Committee. Said amendment must be effective prior to execution of the work.
Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.
