Agreement Suspension. The agreement may be suspended by initiative of the participant or of the organisation if exceptional circumstances — in particular force majeure (see Article 17) — make implementation impossible or excessively difficult. The agreement may be suspended always with the agreement of the other party and at the date convened by both following an amendment and it may be resumed afterwards. The suspension will take effect on the day agreed by the parties. The organisation may — at any moment — suspend the agreement, if the participant has committed or is suspected of having committed: substantial errors, irregularities or fraud or serious breach of obligations under this Agreement or during its award (including improper implementation of the action, submission of false information, failure to provide required information, breach of ethics rules (if applicable), etc.). The suspension will take effect the day after the notification is sent. Once circumstances allow for implementation to resume, the parties must immediately agree on the resumption date (one day after suspension end date). The suspension will be lifted with effect from the suspension end date. During the suspension, no financial support will be paid to the participant. The participant may not claim damages due to suspension by the organisation. If the participant believes the payment is being unduly withheld, the participant may expose the situation to the competent National Agency, after trying to obtain clarification from the organisation and/or when the dispute cannot be solved amicably. Financial support suspension does not affect the organisation’s right to terminate the financial support (see Article 15).
Agreement Suspension. Suspension of this Agreement may occur if in the sole judgment of the Service there is a violation of law or policy or risk to resources or public health and safety. Friends may appeal any such suspension of this Agreement in writing, and the Service shall within 15 days of such an appeal provide a written justification for the suspension, and state what corrective actions would be necessary to reinstate this Agreement.
Agreement Suspension. Owner may order the Contractor in writing to suspend, delay or interrupt all or any part of the Contract Work for such period of time as may be determined to be appropriate. If such suspension, delay or interruption is unreasonable, then Contractor may be entitled to an equitable adjustment. The short/incidental/reasonable stoppage of the Contract Work shall not be deemed suspension, delay, or interruption of work. The Contract price shall not be adjusted for any suspension, delay or interruption to the extent that the performance of the Contract is, was or would have been so suspended, delayed or interrupted by the fault or neglect of the Contractor, by a cause for which the Contractor is responsible, or by a cause for which the Contractor is entitled only to a time extension under this Contract.
Agreement Suspension. Owner may order the Contractor in writing to suspend, delay or interrupt all or any part of the Contract Work for such period of time as may be determined to be appropriate. If such suspension, delay or interruption is unreasonable, then Contractor may be entitled to an equitable adjustment. The short/incidental/reasonable stoppage of the Contract Work shall not be deemed suspension, delay, or interruption of work. Contractor is required to respond to all RFPs issued by an Owner under this Agreement. Contractor shall, at minimum, either: 1) Submit a written proposal in accordance with the requirements contained in the RFP; or 2) Provide written notice (Notice of Declination) stating reasonable, realistic, and verifiable basis for its inability to participate in a RFP process. Failure of a Contractor to submit a proposal, or submit a written notice (Notice of Declination) stating reasonable, realistic, and verifiable basis for its inability to submit a proposal on three (3) occasions during any twelve month period of performance under this agreement shall be considered a material breach of this Agreement and shall entitle PSFA to suspend or terminate Contractor's participation in this Agreement. (Reference: Sections 13-1-177 and 00-0-000 XXXX 1978) The following are examples of Notice of Declination basis:
Agreement Suspension. A temporary hold which is placed on Sponsorship Application submissions when this Agreement has been suspended whether initiated by the SAH or IRCC.
Agreement Suspension. The agreement may be suspended by initiative of the participant or of the organisation if exceptional circumstances - in particular farce majeure (see Article 17) - make irnplementation impossible or excessively difficult. The agreement may be suspended always with the agreement of the other party and at the date convened by both following an arnendment and it may be resumed afterwards. The suspension will take effect on the day agreed by the parties. The organisation may - at any moment - suspend the agreement, if the participant has committed or is suspected of having committed: substantial errors, irregularities or fraud or serious breach of obligations under this Agreement or during its award (including irnproper implementation of the action, submission of false information, failure to provide required information, breach of ethics rules (if applicable), etc.). The suspension will take effect the day after the notification is sent. Once circumstances allow for irnplementation to resume, the parties must irnmediately agree onthe resumption date (one day after suspension end date). The suspension will be lifted with effect from the suspension end date. During the suspension, no financial support will be paid to the participant. The participant may not clairn damages due to suspension by the organisation. E_u_roP-ean Solidarity CorP-s - Tem late for agreements to be used between partner and participants - 2023 • EUROPEAN SOLIDARITY CORPS I xxxxx participant believes the payment·is being unduly withheld, the participant may expose the situation to the competent National Agency, after trying to obtain clarification from the organisation and/or when the dispute cannot be solved amicably. Financial support suspension does not affect the organisation's right to terminate the financial support (see Article 15).
Agreement Suspension. 4.1 The parties hereto acknowledge each to the other that this Agreement is dependent upon AMERICAN BENEFITS GROUP, INC. being able to continue it's mining operations in the Democratic Republic of Madagascar and elsewhere, if so commenced in the future, and in the event that AMERICAN BENEFITS GROUP, INC. is, through causes not within it's reasonable control, unable to continue it's mining operations or any portion thereof and the contract between AMERICAN BENEFITS GROUP, INC. and ABFG is suspended then and in that event ABFG shall forthwith provide written notice of same to April at April's Address for Service herein provided and this Agreement shall , in accordance with said Notice, be immediately suspended provided that ABFG shall be liable to April for all salaries of April employees directly performing services on behalf of ABFG for a period of THIRTY (30) days thereafter, the cost for all transportation in returning said employees to Canada, that all insurance programs in place for April employees shall be kept in good standing by ABFG for the duration of this Agreement's suspension and any costs attributable to ABFG incurred as at the date of Agreement Suspension by April shall be reimbursed April by ABFG.
Agreement Suspension. In the event of a material breach, default, or violation of any term or condition of this Master Agreement by the Agency, ADE shall provide written notice to the Agency and said notice shall set forth the factual basis for the determination that a breach has occurred. If the breach is not remedied within fifteen (15) days of the Agency’s receipt of notice, this Master Agreement may be suspended, at the option of ADE and ADE may no longer provide data to the Agency. If this Master Agreement is suspended, the Agency shall return or destroy/delete any PII in its custody or control immediately.
Agreement Suspension. Contractor is required to respond to all RFPs' issued by an Owner under this Agreement. Contractor shall, at minimum, either: 1) Submit a written proposal in accordance with the requirements contained in the RFP; or 2) Provide written notice (Notice of Declination) stating reasonable, realistic, and verifiable basis for its inability to participate in a RFP process. Failure of a Contractor to submit a proposal, or submit a written notice (Notice of Declination) stating reasonable, realistic, and verifiable basis for its inability to submit a proposal on three (3) occasions during any twelve month period of performance under this agreement shall be considered a material breach of this Agreement and shall entitle PSFA to suspend or terminate Contractor's participation in this Agreement. (Reference: Sections 13-1-177 and 13-1-178 NMSA 1978) The following are examples of Notice of Declination basis: Contract #GTMT-07-2014 Agreement #GTMT-07-2014-AFW2
Agreement Suspension. Suspension of the agreement may occur if in the sole judgment of the Service there is a violation of law or policy or risk to resources or public health and safety.
