Adjustment of the. Contract Sum shall include profit. No adjustment shall be made to the extent .1 that performance is, was, or would have been, so suspended, delayed, or interrupted, by another cause for which the Contractor is responsible; or .2 that an equitable adjustment is made or denied under another provision of the Contract.
Adjustment of the. Subcontract Sum shall include profit on the increased cost of performance caused by suspension, delay, or interruption. No adjustment shall be made to the extent that .1 performance is, was or would have been so suspended, delayed, or interrupted by another cause for which the Subcontractor is responsible; or .2 an equitable adjustment is made or denied under another provision of the Subcontract.
Adjustment of the annual premium: New persons who join during the insurance year shall be insured automatically. The annual premium shall be adjusted retroactively each year to reflect the number of insured employees according to the list of names submitted to Fortuna by the policyholder. This list must be provided 30 days before the Annual Due Date (by the end of November of each year) and shall serve as the basis for calculating the provisional annual premium for the following contractual year. If the number of Insured Persons according to the list provided is lower than the number declared at the beginning of the year, Fortuna shall issue a credit note to the policyholder (final premium invoice). If the number of Insured Persons is higher than the number declared at the beginning of the year, the annual premium for the insurance year will be increased and invoiced by Xxxxxxx (final premium invoice). Art. 5 Place of jurisdiction and applicable law The parties have elected the courts of the canton of Geneva as the place of jurisdiction for all claims and disputes arising in connection with this contract. Swiss law shall apply exclusively.
Adjustment of the. Contract Sum shall include profit. No adjustment shall be made to the extent .1 that perfonnance is, was or would have been so suspended, delayed or intetrupted by another cause for which the Contractor is responsible; or .2 that an equit1ble adjustment is made or denied under another provision of the Contract.
Adjustment of the. Contract Sum shall include Design-Builder’s Fee. No adjustment shall be made to the extent: .1 that performance is, was or would have been so suspended, delayed or interrupted by another cause for which the Design-Builder is responsible; or .2 that an equitable adjustment is made or denied under another provision of the Design-Build Contract.
Adjustment of the maximum evolution rate of Fees based on quality of service The QDS(n) adjustment factor is based on a bonus-malus points system. For each indicator included under II.2.1-A and for each year in which the objectives defined under II.2.3 apply, a Minimum Level of the indicator corresponding to the level under which the penalty is capped is set. Also, a Maximum Level at which bonus points are capped is also defined. Lastly, in the case where the indicator is equal to the Target Level defined under II.2.3, the bonus-penalty point value is nil. At either end of the target level, the bonus-penalty point varies in a linear way between the Maximum and Minimum levels respectively, according to the formulae defined in appendix 5 of this agreement. The Maximum and Minimum Levels of each indicator are also defined in the appendix for each year in which they apply. The caps on the bonus and penalty points associated with each of these indicators are as follows: - Indicator A-1: 0.1%; - Indicator A-2: 0.1%; - Indicator A-3: 0.1%; - Indicator A-4: 0.1%; - Indicator A-5: 0.1%; - Indicator A-6: 0.1%; - Indicator A-7: 0.1%; - Indicator A-8: 0.1%; - Indicator A-9: 0.1%; - Indicator A-10: 0.1%. The methods for calculating the QDS(n) factor are specified in Appendix 5.
Adjustment of the. Consideration subsequent to the Execution Date Should it become clear according to the Agreed Data that –
Adjustment of the. Maximum Pricing Evolution of the Principal Fees depending on the Completion of the Investment Program 13 III.2.4 Conditions of Evolution of the Ancillary Fees 13 III.3 Pricing Policy 14 III.3.1 Pricing Structure 14 III.3.2 Adjustments for General Interest Reasons 14 III.4 Creation of New Fees, Transfers between Categories of Fees, New Services 15 III.4.1 Modification of the Conditions of Pricing of Existing Services 15 III.4.2 New Services or Cost Variation 15 IV Title IV: Discussion with Users 17 IV.1 Economic Consultative Commission 17 IV.2 Follow-Up of the Major Investment Transactions 18 V Title V: Terms and Conditions of Performance of the Agreement 19
