ADDITIONAL PLANS PER PHASE. 1. Halff will:
ADDITIONAL PLANS PER PHASE Sample Clauses
Related to ADDITIONAL PLANS PER PHASE
Final Plans On or before thirty (30) days following the date of full execution of this Lease, Landlord shall submit to Tenant two (2) sets of Landlord’s proposed space and construction plans and specifications prepared by Landlord’s architect, for the Tenant Improvements, Within three (3) business days after receipt of Landlord’s plans and specifications Tenant shall either: (a) evidence its approval by endorsement on one (1) set of said plans and specifications (and return such signed or initialed set to Landlord); or (b) indicate those revisions or corrections which Tenant requires and the reasons therefor; provided Landlord shall not be obligated to accept any revisions which Landlord shall reasonably determine: (i) do not conform to the standards of design, motif and decor reasonably established or adopted by Landlord for the Building; (ii) would subject Landlord or the Premises to any additional cost, expense, liability, violation, fine, penalty, or forfeiture; would adversely affect the reputation, character, or nature of the Building; (iii) would provide for or require any installation of work which is or might be unlawful, create an unsound or dangerous condition, adversely affect the structural soundness of the Premises or Building; (iv) interfere with or abridge the use and enjoyment of any adjoining or other space in the Building, or (v) is of a special use or nature with little or no residual value (unless Tenant agrees to pay for such improvements and the removal thereof upon the expiration or earlier termination of this Lease). Landlord shall, within five (5) days thereafter, submit four (4) sets of proposed plans and specifications, as so revised or corrected, to Tenant for its approval in accordance with this paragraph, which plans will then be considered the final plans (the “Final Plans”). The Final Plans may subsequently be amended by Tenant provided that significant changes will require Landlord’s prior written approval, which approval shall be given or reasonably refused within five (5) business days after receipt of such amended plans and specifications and, provided further that if such change order will delay the anticipated Commencement Date specified in Section 1 of the Lease the change order shall be considered a Tenant Delay (as hereinafter defined). The parties will work cooperatively to complete the plan approval process expeditiously.
Annual Work Plans and Budgets The Recipient shall furnish to the Association as soon as available, but in any case not later than September 1 of each year, the annual work plan and budget for the Project for each subsequent year of Project implementation, of such scope and detail as the Association shall have reasonably requested, except for the annual work plan and budget for the Project for the first year of Project implementation, which shall be furnished no later than one (1) month after the Effective Date.
Site Allowance All new construction and extension/refurbishment work having a project value in excess of $2.0m will attract the then current City of Melbourne Site Allowance.
Educator Plans: Improvement Plan A) An Improvement Plan is for those Educators with PTS whose overall rating is unsatisfactory.
Service Core Allowance The company shall pay $0.95 per hour for all work carried out in construction of service core. This allowance will be adjusted annually (effective from 1 June) in accordance with CPI movements (All Groups, Melbourne) for the preceding 12 months to March (increases to be rounded to the nearest 5 cents).
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Improvement Plans a. An improvement plan is a clearly articulated assistance program for a teacher/counselor/SLP whose overall summative rating is ineffective.
Uniform Maintenance Allowance 22.1 The City provides uniforms or uniform allowance for employees represented by the Association. The City will continue to replace, repair and maintain uniforms worn in the line of duty. The average cost of the uniforms/uniform allowances are reported as special compensation (for those employees defined as “classic employees” by the Public Employees’ Pension Reform Act of 2013 for retirement calculation purposes and is currently reported as $17 per pay period.
Periodic Progress Payments The Owner shall make progress payments, less retainage, as set forth in Section 4 of the General Conditions.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
