Additional Conditions For each mediation or arbitration:
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Landlord's Waiver Prior to the Bank making the first Revolving Loan, the Borrower will obtain, and will thereafter maintain in effect at all times, waivers from the owners of all premises in which any material amount of Collateral is located, such waivers to be in form and substance satisfactory to the Bank.
Additional Conditions Precedent No Lender has any obligation to make any Loan (including its first), and LC Issuer has no obligation to issue any Letter of Credit (including its first), unless the following conditions precedent have been satisfied:
Landlord's Waivers Any lessor of Tenant's Personal Property may, upon notice to Landlord and during reasonable hours, enter the Property and take possession of any of Tenant's Personal Property without liability for trespass or conversion upon a default by Tenant, provided that such lessor provide Landlord with the opportunity to cure the defaults of Tenant on terms and conditions satisfactory to such lessor and Landlord.
Time of the Essence in This Tenant Work Letter Unless otherwise indicated, all references herein to a “number of days” shall mean and refer to calendar days. If any item requiring approval is timely disapproved by Landlord, the procedure for preparation of the document and approval thereof shall be repeated until the document is approved by Landlord.
Additional Conditions to Closing (a) All necessary approvals under federal and state securities laws and other authorizations relating to the issuance of the Acquisition Shares and the transfer of the Shares shall have been received.
Condition of Premises The Premises are demised to Tenant and Tenant accepts the same “as-is”, except that (a) if, not later than sixty (60) days following the date of this Lease, Tenant notifies Landlord that the Initial Premises or a portion thereof (clearly designated in such notice to Landlord) are to be delivered in shell condition (but absent such notice Landlord will not otherwise be obligated to perform the Shell Work, time being of the essence of such notice), the Landlord shall, with respect to such designated portion(s) of the Premises, perform the Shell Work described in Exhibit B-1 at Landlord’s sole cost and expense prior to September 1, 2013, and all other work necessary to prepare the Initial Premises for Tenant’s occupancy shall be performed at Tenant’s sole cost and expense, in accordance with the applicable provisions of this Lease and (b) as to space added to the Premises pursuant to Section 42.01, if Tenant elects as provided therein, that some or all of the space so added shall be delivered in shell condition (but absent such notice Landlord will not otherwise be obligated to perform the Shell Work, time being of the essence of such notice), the Landlord shall, with respect to such designated portion(s) of the Premises, perform the Shell Work described in Exhibit B-1 at Landlord’s sole cost and expense prior to the date which is ninety (90) days following the date on which the additional space would be delivered under Section 42.01 but for the Tenant election that the same be delivered in shell condition, and all other work necessary to prepare the space so added under Section 42.01 for Tenant’s occupancy shall be performed at Tenant’s sole cost and expense, in accordance with the applicable provisions of this Lease. Tenant’s taking possession of any portion of the Premises shall be conclusive evidence that such portion of the Premises was in good order and satisfactory condition when Tenant took possession, and except for latent defects not readily apparent from a careful inspection of the Premises without cutting into or otherwise disturbing walls, floors or ceilings and punchlist items of which Tenant has delivered notice to Landlord, excluding items of damage caused by Tenant or its agents, independent contractors or suppliers (subject to the provisions of Section 3.01 of this Lease). No promise of Landlord to alter, remodel or improve the Property and no representation by Landlord or its agents respecting the condition of the Property has been made to Tenant or relied upon by Tenant other than as may be contained in this Lease or in any written amendment hereto signed by Landlord and Tenant.
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Performance of Landlords Work (a) Definition of Landlord’s Work. As used herein, “
