Additional Attachments and/or Assurances Applicable to this Work Sample Clauses

Additional Attachments and/or Assurances Applicable to this Work. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional ttachments/Assurances”. Otherwise, remove this section if not applicable. In Scope: XXXXXXXXXX Deliverables and Services Produced XXXXXXXXXXX Phases (Remove or add if not needed) Approach (modify as needed) Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off.
Sample 1Sample 2Sample 3See All (26)
AutoNDA by SimpleDocs

Related to Additional Attachments and/or Assurances Applicable to this Work

  • AMENDMENTS TO THIS AGREEMENT This Agreement may only be amended by the parties in writing.

  • Execution of Additional Agreements In executing, or accepting the agencies created by, any additional agreement permitted by this Agreement, or the modifications of the agencies created by this Agreement, the Global Agent shall be entitled to conclusively rely upon a written opinion of counsel stating that the execution of such additional agreement is authorized or permitted by this Agreement, that all conditions precedent to such additional agreement have been satisfied and that such additional agreement constitutes the legal, valid and binding obligation of Issuer enforceable in accordance with its terms and subject to customary exceptions.

  • AMENDMENTS TO THIS CONTRACT 8.1 No amendment to the provisions of this Contract, other than a variation of the Charges in accordance with the Charges Variation Procedure or a variation of any Sub-Contractors in accordance with Clause 30.5, shall be effective unless made in accordance with the Contract Change Procedure specified in Schedule 2-7.

  • Deadlines for Providing Insurance Documents after Renewal or Upon Request As set forth herein, certain insurance documents must be provided to the OGS Procurement Services contact identified in the Contract Award Notice after renewal or upon request. This requirement means that the Contractor shall provide the applicable insurance document to OGS as soon as possible but in no event later than the following time periods:  For certificates of insurance: 5 business days  For information on self-insurance or self-retention programs: 15 calendar days  For other requested documentation evidencing coverage: 15 calendar days  For additional insured and waiver of subrogation endorsements: 30 calendar days Notwithstanding the foregoing, if the Contractor shall have promptly requested the insurance documents from its broker or insurer and shall have thereafter diligently taken all steps necessary to obtain such documents from its insurer and submit them to OGS, OGS shall extend the time period for a reasonable period under the circumstances, but in no event shall the extension exceed 30 calendar days.

  • COST PRINCIPLES AND ADMINISTRATIVE REQUIREMENTS A. CONSULTANT agrees that the Contract Cost Principles and Procedures, 48 CFR, Federal Acquisition Regulations System, Chapter 1, Part 31.000 et seq., shall be used to determine the cost allowability of individual items.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2

  • Compliance with Consensus Policies and Temporary Policies Registry Operator shall comply with and implement all Consensus Policies and Temporary Policies found at <xxxx://xxx.xxxxx.xxx/general/consensus-­‐policies.htm>, as of the Effective Date and as may in the future be developed and adopted in accordance with the ICANN Bylaws, provided such future Consensus Polices and Temporary Policies are adopted in accordance with the procedure and relate to those topics and subject to those limitations set forth in Specification 1 attached hereto (“Specification 1”).

  • WAIVER OF LIABILITY, ASSUMPTION OF RISK, AND INDEMNITY AGREEMENT I, , IN CONSIDERATION of being permitted to participate in any way in the Rocky Mountain Cycling Club 200 km brevet calendared for October 8, 2022 (“Activity”), I hereby acknowledge, agree, attest and represent the following:

  • AMENDMENTS REQUIRED BY PRIME CONTRACT XXXXXX agrees that upon the request of LOCKHEED XXXXXX it will negotiate in good faith with LOCKHEED XXXXXX relative to amendments to this Contract to incorporate additional provisions herein or to change provisions hereof, as LOCKHEED XXXXXX may reasonably deem necessary in order to comply with the provisions of the applicable Prime Contract or with the provisions of amendments to such Prime Contract. If any such amendment to this Contract causes an increase or decrease in the cost of, or the time required for, performance of any part of the Work under this Contract, an equitable adjustment shall be made pursuant to the "Changes" clause of this Contract.

  • Assumption of Risk, and Indemnity Agreement Waiver: In consideration of being permitted to visit or participate in any way in any activity, including transportation, at the above location, I, for myself, my heirs, personal representatives or assigns, do hereby release, waive, discharge, and covenant not to xxx The Regents of the University of California, its officers, employees, and agents from liability from any and all claims including the negligence of The Regents of the University of California, its officers, employees, and agents, resulting in personal injury, accidents or illnesses (including death), and property loss arising from, but not limited to, visitation or participation in any way in any activity, including transportation, at the above location. Assumption of Risks: Visitation or participation carries with it certain inherent risks that cannot be eliminated regardless of the care taken to avoid injuries. The specific risks vary from one activity to another, but the risks range from 1) minor injuries such as scratches, bruises, and sprains to 2) major injuries such as eye injury or loss of sight, joint or back injuries, heart attacks, and concussions to 3) catastrophic injuries including paralysis and death. I have read the previous paragraphs and I know, understand, and appreciate these and other risks that are inherent in visitation or participation. I hereby assert that my visitation or participation is voluntary and that I knowingly assume all such risks. Indemnification and Hold Harmless: I also agree to INDEMNIFY AND HOLD The Regents of the University of California HARMLESS from any and all claims, actions, suits, procedures, costs, expenses, damages and liabilities, including attorney’s fees brought as a result of my involvement in visitation or participation and to reimburse them for any such expenses incurred.

Time is Money Join Law Insider Premium to draft better contracts faster.