Construction of Tenant Improvements by Tenants Agents Construction Contract; Cost Budget. Prior to Tenant's execution of ---------------------------------- the construction contract and general conditions with Contractor (the "Contract"), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred, or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through ---------------- 2.2.1.8 above, in connection with the design and construction of the Tenant ------- Improvements to be performed by or at the direction of Tenant or the Contractor (which costs form a basis for the amount of the Contract, if any (the "Final Costs"). Prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with a completion bond in an amount equal to the Final Costs to ensure Landlord of the completion of the Tenant Improvements.
Alterations by Tenant Tenant shall not make any alterations, additions or improvements (“Alterations”) to the Premises without Landlord’s prior written consent, except for nonstructural Alterations that cost $5,000 or less and are not visible from the exterior of the Premises. All Alterations installed by Tenant shall be new or completely reconditioned. Landlord shall have the right to approve the contractor, the method of payment of the contractor, and the plans and specifications for all proposed Alterations. Tenant shall obtain Landlord’s consent to all proposed Alterations requiring Landlord’s consent prior to the commencement of any such Alterations. Tenant’s request for consent shall be accompanied by information identifying the contractor and method of payment and two (2) copies of the proposed plans and specifications. All Alterations of whatever kind and nature shall become at once a part of the realty and shall be surrendered with the Premises upon expiration or earlier termination of the Lease Term, unless Landlord requires Tenant to remove the same as provided in Article 20. If Tenant demolishes or removes any then-existing tenant improvements or other portions of the Premises or the Building (including without limitation any previously installed Alterations), Tenant shall promptly commence and diligently pursue to completion the Alterations then underway or shall otherwise restore the Premises and the Building to its condition and state of improvement prior to such demolition or removal. During the Lease Term, Tenant agrees to provide, at Tenant’s expense, a policy of insurance covering loss or damage to Alterations made by Tenant, in an amount adequate to repair or replace the same, naming Landlord as an additional insured. Provided, however, Tenant may install movable furniture, trade fixtures, machinery or equipment in conformance with applicable governmental rules or ordinances and remove the same upon expiration or earlier termination of this Lease as provided in Article 20.
Repairs by Tenant Tenant shall, at its sole cost and expense, promptly perform all maintenance, repairs, refurbishing and replacement work to the Leased Premises that are not Landlord’s express responsibility under this Lease, and shall keep the Leased Premises in good condition and repair, reasonable wear and tear excepted. Tenant’s repair obligations include repairs to: (a) floor covering, (b) interior partitions, (c) doors, (d) the interior side of demising walls, (e) electronic, phone and data cabling and related equipment that is installed by or for the exclusive benefit of Tenant and located in the Leased Premises or other portions of the Building, (f) supplemental air conditioning units, private showers and kitchens, including hot water heaters, plumbing and similar facilities serving Tenant exclusively, and (g) alterations performed by contractors retained by Tenant, including related HVAC balancing. All Tenant’s work shall be performed in accordance with the rules and procedures described in Section 5.2 hereof. Upon termination of this Lease, Tenant will surrender and deliver the Leased Premises to Landlord in the same condition in which the Leased Premises existed on the Commencement Date, subject, however, to (i) the provisions of Article VI hereof, (ii) the alterations permitted pursuant to this Lease, (iii) the provisions of Section 5.3, and (iv) except for ordinary wear and tear. If Tenant should fail or refuse to make such repairs, refurbishings or replacements or perform said maintenance as and when reasonably required, Landlord may, at its option, but without any obligation to do so, cure such failure or refusal and Landlord’s costs shall be reimburseable by Tenant as additional rent, by Tenant, immediately upon invoicing by Landlord. Notwithstanding the foregoing, Landlord agrees to perform, as Above Standard Services, Tenant’s repair and maintenance obligations with respect to the Leased Premises. Tenant shall notify Landlord of the need for any such repair and maintenance and Landlord shall endeavor to respond timely to each such request.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.
Maintenance and Repairs by Tenant Tenant, at its expense, shall --------------------------------- maintain and repair the interior of the Leased Premises, and all heating, air conditioning, ventilating, electrical, mechanical, sprinkler and plumbing systems, equipment, machinery or fixtures exclusively servicing the Leased Premises, together with all pipes, conduits, ducts and drains therefor. Furthermore Tenant, at its expense, shall replace any broken glass in the interior or exterior of the Leased Premises, and shall maintain and repair all entryway doors to the Leased Premises. Landlord shall assign to Tenant all assignable manufacturers' warranties with respect to equipment and fixtures installed in the Leased Premises. Tenant further agrees to keep the Leased Premises in good, tenantable, sanitary, sightly and clean condition and to keep all lobbies and entryways which are part of the Leased Premises clean and free from debris, refuse, obstructions or hazardous conditions. Tenant agrees to notify Landlord in the event an excessive amount of snow accumulates on the roof of the Leased Premises. Tenant shall be responsible for all maintenance or repairs wholly or partially (to the extent of Tenant's part) caused by the negligence or fault of Tenant or any of its agents, visitors or licensees, or by Tenant's breach of any provision of this Agreement. If Tenant does not make the repairs or perform the maintenance required hereunder in a prompt and adequate manner, then after notice to Tenant and opportunity cure as provided herein, Landlord may make such repairs or perform such maintenance and pay the costs thereof, and such costs shall be so much Additional Rent which shall become immediately due and payable by Tenant to Landlord.
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
