ACCEPTANCE OF NONCONFORMING WORK If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.
Acceptance and Application of Partial Payments Lender may accept and either apply or hold in suspense Partial Payments in its sole discretion in accordance with this Section 2. Lender is not obligated to accept any Partial Payments or to apply any Partial Payments at the time such payments are accepted, and also is not obligated to pay interest on such unapplied funds. Lender may hold such unapplied funds until Borrower makes payment sufficient to cover a full Periodic Payment, at which time the amount of the full Periodic Payment will be applied to the Loan. If Borrower does not make such a payment within a reasonable period of time, Lender will either apply such funds in accordance with this Section 2 or return them to Borrower. If not applied earlier, Partial Payments will be credited against the total amount due under the Loan in calculating the amount due in connection with any foreclosure proceeding, payoff request, loan modification, or reinstatement. Lender may accept any payment insufficient to bring the Loan current without waiver of any rights under this Security Instrument or prejudice to its rights to refuse such payments in the future.
ACCEPTANCE OF DEFECTIVE OR NON-CONFORMING WORK 13.3.1 The State may accept defective or nonconforming Work pursuant to Paragraph 13.2.1
ACCEPTANCE OF INCOMPLETE OR NON-CONFORMING DELIVERABLES If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City’s evaluation of and determination to accept such defective or non-conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non-conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor.
Nonconforming Work 23.1.1 Developer shall promptly remove from Premises all Work identified by District as failing to conform to the Contract Documents whether incorporated or not. Developer shall promptly replace and re-execute its own Work to comply with the Contract Documents without additional expense to the District and shall bear the expense of making good all work of other contractors destroyed or damaged by any removal or replacement pursuant hereto and/or any delays to the District or other contractors caused thereby.
Inspection and Rejection of Nonconforming Goods (a) Buyer shall inspect the goods within five days of receipt (“Inspection Period”). Xxxxx will be deemed to have accepted the goods unless it notifies Seller in writing of any Nonconforming Goods during the Inspection Period and furnishes documentation reasonably required by Seller. “
For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.
361 Acceptance of Specified Roads Specified Road work may be accepted subject to completion of clearing work that does not affect the road structure when completion is delayed for reasons beyond control of Purchaser, such as adverse weather. Specified Road work may be accepted subject to completion of planting and seeding for soil stabilization when completion is delayed for reasons beyond control of Purchaser, such as seasonal limitations. Purchaser shall complete planting or seeding on such road during the next suitable planting season. Specified Road work may be conditionally accepted prior to the application of dust palliatives when application is not necessary to prevent dusting of the road surface due to climatic conditions. Purchaser shall apply dust palliative on such roads prior to use during periods when dusting may occur. Prior to request for final inspection, Specified Road work, roadways, borrow pits, and quarries, occupied and no longer needed by Purchaser in connection with Purchaser’s Operations, shall be cleared of all rubbish, excess materials, and temporary structures.
NOTICE OF CHANGE OR CANCELLATION There shall be no cancellation, material change, exhaustion of aggregate limits, or intent not to renew insurance coverage, either in whole or in part, without at least sixty (60) days prior written Legal Notice by Contractor to Enterprise Services. Failure to provide such notice, as required, shall constitute default by Contractor. Any such written notice shall include the Master Contract number stated on the cover of this Master Contract.
NON-ACCEPTANCE OF SETTLEMENT AGREEMENT 33. If, for any reason whatsoever, this Settlement Agreement is not accepted by the Hearing Panel or an Order in the form attached as Schedule “A” is not made by the Hearing Panel, each of Staff and the Respondent will be entitled to any available proceedings, remedies and challenges, including proceeding to a disciplinary hearing pursuant to sections 20 and 24 of By- law No. 1, unaffected by this Settlement Agreement or the settlement negotiations.
