361 Acceptance of Specified Roads Sample Clauses

361 Acceptance of Specified Roads. Specified Road work may be accepted subject to completion of clearing work that does not affect the road structure when completion is delayed for reasons beyond control of Purchaser, such as adverse weather. Specified Road work may be accepted subject to completion of planting and seeding for soil stabilization when completion is delayed for reasons beyond control of Purchaser, such as seasonal limitations. Purchaser shall complete planting or seeding on such road during the next suitable planting season. Specified Road work may be conditionally accepted prior to the application of dust palliatives when application is not necessary to prevent dusting of the road surface due to climatic conditions. Purchaser shall apply dust palliative on such roads prior to use during periods when dusting may occur. Prior to request for final inspection, Specified Road work, roadways, borrow pits, and quarries, occupied and no longer needed by Purchaser in connection with Purchaser’s Operations, shall be cleared of all rubbish, excess materials, and temporary structures.
Sample 1Sample 2Sample 3See All (88)
AutoNDA by SimpleDocs
361 Acceptance of Specified Roads. Specified Road work may be accepted subject to com- pletion of clearing work that does not affect the road structure when completion is delayed for reasons be- yond control of Contractor, such as adverse weather. Specified Road work may be accepted subject to completion of planting and seeding for soil stabilization when completion is delayed for reasons beyond control of Contractor, such as seasonal limitations. Contractor shall complete planting or seeding on such road during the next suitable planting season. Specified Road work may be conditionally accepted prior to the application of dust palliatives when applica- tion is not necessary to prevent dusting of the road sur- face due to climatic conditions. Contractor shall apply dust palliative on such roads prior to use during periods when dusting may occur. Prior to request for final inspection, Specified Road work, roadways, borrow pits, and quarries, occupied and no longer needed by Contractor in connection with Contractor’s Operations, shall be cleared of all rubbish, excess materials, and temporary structures.
Sample 1Sample 2Sample 3See All (20)
361 Acceptance of Specified Roads. Specified Road work may be accepted subject to comple- tion of clearing work that does not affect the road structure when completion is delayed for reasons beyond control of Contractor, such as adverse weather. Specified Road work may be accepted subject to com- pletion of planting and seeding for soil stabilization when completion is delayed for reasons beyond control of Con- tractor, such as seasonal limitations. Contractor shall com- plete planting or seeding on such road during the next suit- able planting season. Specified Road work may be conditionally accepted prior to the application of dust palliatives when application is not necessary to prevent dusting of the road surface due to climatic conditions. Contractor shall apply dust palliative on such roads prior to use during periods when dusting may occur. Prior to request for final inspection, Specified Road work, roadways, borrow pits, and quarries, occupied and no longer needed by Contractor in connection with Con- tractor’s Operations, shall be cleared of all rubbish, excess materials, and temporary structures.
Sample 1Sample 2Sample 3See All (6)
361 Acceptance of Specified Roads. Specified Road work may be accepted subject to com- pletion of clearing work that does not affect the road structure when completion is delayed for reasons be- yond control of Contractor, such as adverse weather.‌‌ Specified Road work may be accepted subject to completion of planting and seeding for soil stabilization when completion is delayed for reasons beyond control of Contractor, such as seasonal limitations. Contractor shall complete planting or seeding on such road during the next suitable planting season. Specified Road work may be conditionally accepted prior to the application of dust palliatives when applica- tion is not necessary to prevent dusting of the road sur- face due to climatic conditions. Contractor shall apply dust palliative on such roads prior to use during periods when dusting may occur.‌‌ Prior to request for final inspection, Specified Road
Sample 1
361 Acceptance of Specified Roads. Specified Road work may be accepted subject to completion of clearing work that does not affect the road structure when completion is delayed for reasons beyond control of Purchaser, such as adverse weather. Specified Road work may be accepted subject to completion of planting and seeding for soil stabilization obtain prior approval from Contracting Officer as to the location for such cleaning and measures, if any, for controlling impacts.
Sample 1

Related to 361 Acceptance of Specified Roads

  • ACCEPTANCE OF NONCONFORMING WORK If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.

  • NON-ACCEPTANCE OF SETTLEMENT AGREEMENT 33. If, for any reason whatsoever, this Settlement Agreement is not accepted by the Hearing Panel or an Order in the form attached as Schedule “A” is not made by the Hearing Panel, each of Staff and the Respondent will be entitled to any available proceedings, remedies and challenges, including proceeding to a disciplinary hearing pursuant to sections 20 and 24 of By- law No. 1, unaffected by this Settlement Agreement or the settlement negotiations.

  • Acceptance of the Terms of Use These terms of use are entered into by and between You and InterPayments Inc ("Company," "we," or "us"). The following terms and conditions, together with any documents they expressly incorporate by reference (collectively, "Terms of Use"), govern your access to and use of xxx.xxxxxxxxxxxxx.xxx, including any content, functionality, and services offered on or through xxx.xxxxxxxxxxxxx.xxx (the "Website"), whether as a guest or a registered user. Please read the Terms of Use carefully before you start to use the Website. By using the Website or by clicking to accept or agree to the Terms of Use when this option is made available to you, you accept and agree to be bound and abide by these Terms of Use and our Privacy Policy, found at Privacy Policy, incorporated herein by reference. If you do not want to agree to these Terms of Use or the Privacy Policy, you must not access or use the Website. This Website is offered and available to users who are 18 years of age or older. By using this Website, you represent and warrant that you are of legal age to form a binding contract with the Company and meet all of the foregoing eligibility requirements. If you do not meet all of these requirements, you must not access or use the Website.

  • Final Acceptance When the Project/Service or any portion thereof, as designated by the COUNTY, is ready for its intended use, the COUNTY and any other invited parties shall make an inspection of the Project/Service, to verify its completeness and develop a punch list of items needing completion or correction before final payment will be made. CONTRACTOR shall have ten (10) calendar days to correct all deficiencies. An eighty-dollar ($80.00) re-inspection fee shall be applied for the third inspection and any required re-inspection thereafter. The COUNTY shall have the right to exclude CONTRACTOR from those portions of the work designated as complete after the inspection; provided, however, that CONTRACTOR will have reasonable access for the time allotted by the COUNTY to complete or correct items on the punch list. When the work provided for under this Agreement has been completely performed by CONTRACTOR, and the final inspection has been made by the COUNTY, a final invoice will be prepared by the CONTRACTOR. The amount of this invoice, less any sums that may have been deducted or retained under the provisions of this Agreement, will be paid to CONTRACTOR in accordance with this Agreement, and after CONTRACTOR has agreed in writing to accept the balance due, as determined by the COUNTY, as full settlement of the account under the contract and of all claims in connection therewith. Occupancy by the COUNTY alone does not constitute final acceptance.

  • Acceptance of Services Services furnished under this Contract are subject to acceptance by OSU. If OSU finds services furnished to be incomplete or not in compliance with the Contract, OSU, at its sole discretion, may either reject the services, require Contractor to correct any defects without charge, or negotiate with Contractor to reduce the price, whichever OSU deems appropriate under the circumstances. If Contractor is unable or refuses to cure any defects within a time deemed reasonable by OSU, OSU may reject the services and cancel the Contract in whole or in part.

  • Acceptance of Work Upon Purchaser’s written request and assurance that work has been com- pleted, Forest Service shall perform an inspection within 5 days, excluding weekends and Federal holidays, so as not to delay unnecessarily the progress of Purchaser’s Operations. Such a request may be for acceptance of:

  • Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if:

  • Acceptance of the Work 19.1 The Contractor shall correct any Work that fails to conform to the requirements of the Contract Documents where such failure to conform appears during the progress of the Work, and shall remedy any defects due to faulty permitting, design, materials, equipment or workmanship which appear within a period of one year from the Date of Final Settlement of the Contract or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required by the Contract Documents. The provisions of this Article apply to Work done by Subcontractors as well as to Work done by direct employees of the Contractor, and are in addition to any other remedies or warranties provided by law.

  • INSPECTION, ACCEPTANCE AND REJECTION a. All Goods will be subject to Mercy Corps' inspection and testing (which may be done by a third party authorized by Mercy Corps), at any time and place, including the period of manufacture/production/creation and before final acceptance. If Mercy Corps inspects or tests at Supplier's premises, Supplier, without additional charge, will provide all reasonable facilities and assistance for the safety and convenience of Mercy Corps' inspectors. No inspection or testing done or not done before final inspection and acceptance will relieve Supplier from responsibility for defects or for other failure to meet the requirements of this Agreement. Notwithstanding any prior inspections or payments made, all Goods will be subject to final inspection and acceptance at the Delivery Location within a reasonable time after delivery (but in no event, less than three days after the date of delivery).

  • Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.

Time is Money Join Law Insider Premium to draft better contracts faster.