Cash Damages Sample Clauses

Cash Damages. If (x) (I) within three (3) Trading Days after the Company’s receipt of the facsimile copy of a Conversion Notice or (II) on any Company Delivery Date, the Company shall fail to credit a Holder’s balance account with DTC or issue and deliver a certificate to such Holder for the number of shares of Common Stock to which such Holder is entitled upon such Holder’s conversion or the Company’s conversion, as applicable, of Preferred Shares or (y) within three (3) Trading Days of the Company’s receipt of a Preferred Stock Certificate the Company shall fail to issue and deliver a new Preferred Stock Certificate representing the number of Preferred Shares to which such Holder is entitled pursuant to Section 2(d)(ii), then due to the uncertainty and difficulty of estimating a Holder’s damages for such delay and as a reasonable estimate of such Holder’s actual loss due to the delay and not as a penalty, the Company shall pay additional damages to such Holder for each day after the Share Delivery Date or the Company Delivery Date, as applicable, that such conversion is not timely effected and/or each day after the Preferred Stock Delivery Date that such Preferred Stock Certificate is not delivered in an amount equal to one and one half percent (1.5%) of the product of (I) the sum of the number of shares of Common Stock not issued to the Holder on or prior to the Share Delivery Date or Company Delivery Date, as applicable, and to which such Holder is entitled as set forth in the applicable Conversion Notice or in any Company Conversion Notice and, in the event the Company has failed to deliver a Preferred Stock Certificate to the Holder on or prior to the Preferred Stock Delivery Date, the number of shares of Common Stock issuable upon conversion of the Preferred Shares represented by such Preferred Stock Certificate as of the Preferred Stock Delivery Date and (II) the Closing Sale Price of the Common Stock on the Share Delivery Date or Company Delivery Date, as applicable, in the case of the failure to deliver Common Stock, or the Preferred Stock Delivery Date, in the case of failure to deliver a Preferred Stock Certificate. If the Company fails to pay the additional damages set forth in this Section 2(d)(v)(A) within five (5) Trading Days of the date incurred, then the Holder entitled to such payments shall have the right at any time, so long as the Company continues to fail to make such payments, to require the Company, upon written notice, to immediately issue, in...
Sample 1Sample 2Sample 3See All (58)
AutoNDA by SimpleDocs
Cash Damages. If by the Conversion Share Delivery Date, (A)(x)the Company shall fail to issue and deliver a certificate to the Holder of a Note being converted for, or, (y) if as required by Section 14.02(b) hereof the Transfer Agent shall fail to credit such Holder’s or its designee’s balance account with DTC with, the applicable number of Conversion Shares (free of any restrictive legend, provided, in the case of a conversion other than a Redemption Period Conversion (as to which the last sentence of Section 14.02(h)(ii) applies), that any Unrestricted Condition is satisfied) and (B) in each case of the preceding clause (A)(x) or (A)(y) above, if such failure continues for an additional three (3) Business Days, then, in addition to all other available remedies that such Holder may pursue hereunder, the Company shall pay additional damages to such Holder, in cash, for each 30-day period after the Conversion Share Delivery Date such conversion is not timely effected and/or each 30-day period after the date the Company is obligated to deliver a Physical Note hereunder such Note is not delivered in an amount equal to (prorated for any partial period) (x) in the case of a failure to deliver Conversion Shares, one percent (1.0%) of the product of (I) the number of Conversion Shares not issued and delivered to such Holder or its designee (free of any restrictive legend, provided, in the case of a conversion other than a Redemption Period Conversion (as to which the last sentence of Section 14.02(h)(ii) applies), that any Unrestricted Condition is satisfied) on or prior to the Conversion Share Delivery Date and to which such Holder is entitled and (II) the Volume Weighted Average Price of a share of Common Stock on the Conversion Share Delivery Date and (y) in the case of a failure to deliver a new Note, one percent (1.0%) of the outstanding balance of the new Note; provided that such Holder shall have no right to any such additional damages hereunder to the extent the failure of the Company to deliver such Conversion Shares is caused by such Xxxxxx’s failure to provide complete information required to be provided by such Holder to the Conversion Agent hereunder or the inaccuracy of any such information; provided, however, that the Conversion Agent, on behalf of the Company, shall notify a Holder as promptly as practicable after the Company becomes aware of the fact that information provided by such Holder to the Conversion Agent is inaccurate or incomplete and as promptly pr...
Sample 1Sample 2See All (5)
Cash Damages. If within three (3) Trading Days after the Corporation's receipt of the facsimile copy of a Conversion Notice the Corporation shall fail to credit a Holder's balance account with DTC or issue and deliver a certificate to such Holder for the number of shares of Common Stock to which such Holder is entitled upon such Holder's conversion of Series A Convertible Preferred Stock (a "Conversion Failure"), and if on or after such Trading Day the Holder purchases (in an open market transaction or otherwise) shares of Common Stock to deliver in satisfaction of a sale by the Holder of the shares of Common Stock issuable upon such conversion that the Holder anticipated receiving from the Corporation (a "Buy-In"), then the Corporation shall, within three (3) Trading Days after the Holder's request and in the Holder's discretion, either (i) pay cash to the Holder in an amount equal to the Holder's total purchase price (including brokerage commissions and out-of-pocket expenses, if any) for the shares of Common Stock so purchased (the "Buy-In Price"), at which point the Corporation's obligation to deliver such certificate (and to issue such Common Stock) shall terminate, or (ii) promptly honor its obligation to deliver to the Holder a certificate or certificates representing such Common Stock and pay cash to the Holder in an amount equal to the excess (if any) of the Buy-In Price over the product of (A) such number of shares of Common Stock, times (B) the Closing Sale Price on the Conversion Date. Nothing herein shall limit a Holder's right to pursue any other remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Corporation's failure to timely deliver certificates representing shares of Common Stock upon conversion of the Series A Convertible Preferred Stock as required pursuant to the terms hereof.
Sample 1
Cash Damages. If within three (3) Business Days after the Company's receipt of the facsimile copy of a Conversion Notice or deemed receipt of a Conversion Notice the Company shall fail to issue and deliver a certificate to the Holder for, or credit the Holder's balance account with DTC with, the number of Shares to which the Holder is entitled upon the Holder's conversion of any Conversion Amount, or if the Company fails to issue and deliver a new Note representing the Principal to which such Holder is entitled on or before the Note Delivery Date pursuant to Section 2(c)(ii), then in addition to all other available remedies that the Holder may pursue hereunder and under the Securities Purchase Agreement (including indemnification pursuant to Section 7 thereof), the Company shall pay additional damages to the Holder for each day after the Share Delivery Date such conversion is not timely effected and/or each day after the Note Delivery Date such Note is not delivered in an amount equal to 0.5% of the sum of (a) the product of (I) the number of Shares not issued to the Holder on or prior to the Share Delivery Date and to which the Holder is entitled and (II) the Weighted Average Price of the Common Stock on the Share Delivery Date, and (b) in the event the Company has failed to deliver a Note to the Holder on or prior to the Note Delivery Date, the product of (y) the number of Shares issuable upon conversion of the Principal represented by the Note as of the Note Delivery Date and (z) the Weighted Average Price of the Common Stock on the Note Delivery Date.
Sample 1
Cash Damages. If, on or before the Share Delivery Date, the Borrower shall fail to issue and deliver to the applicable Lender in accordance with Section 2(c)(ii) of this Annex I the number of Option Exchange Shares (free of any restrictive legend or stop transfer instructions) to which such Lender is entitled upon its Exchange of any Exchange Amount, then in addition to all other available remedies that such Lender may pursue hereunder, then the Borrower shall pay as partial liquidated damages to such Lender for each 30-day period (prorated for any partial period) after the Share Delivery Date such Exchange is not timely effected an amount equal to one percent (1%) of the Exchange Amount. Notwithstanding anything to the contrary contained herein (and in addition to the remedies set forth herein), to the extent that the Borrower shall fail to issue and deliver Option Exchange Shares to the applicable Lender prior to the applicable Share Delivery Date, the principal amount of the Indenture Notes to which such failure relates shall continue to bear interest until the date such Option Exchange Shares are actually issued to the applicable Lender. If the Borrower fails to pay the additional damages set forth in this Section 2(c)(v)(A) of this Annex I or interest that accrues in accordance with the immediately preceding sentence or Section 2(c)(iv), in each case, within five (5) Business Days of the date incurred, then the Lender entitled to such payments shall have the right at any time, so long as the Borrower continues to fail to make such payments, to require the Borrower, upon written notice, to immediately issue, in lieu of such damages or interest payments described herein, the number of shares of Common Stock equal to the quotient of (X) the aggregate amount of the damages payments described in this Section 2(c)(v)(A) of this Annex I divided by (Y) the Common Stock Exchange Price in effect on such Exchange Date.
Sample 1
Cash Damages. If within five Business Days after the Holder's delivery of an Exchange Notice (subject to extension in accordance with Section 2(e)(iii) for a good faith dispute made in accordance with the terms of Section 2(e)(iii)) (the "Share Delivery Period"), the Transfer Agent fails to issue a certificate to Broker or credit Broker's balance account with DTC for the number of shares of Common Stock to which the Holder is entitled upon the applicable Exchange Notice (an "Exchange Failure"), in addition to all other available remedies which the Holder may pursue hereunder and under the Securities Purchase Agreement (including indemnification pursuant to Article VIII thereof), the Company shall pay additional damages to the Holder for each day after the end of the Share Delivery Period until Broker receives a certificate or Broker's balance account with DTC is credited with the proper number of shares of Common Stock in an amount equal to 1.5% per month of the applicable Exchange Amount submitted for exchange by the Holder.
Sample 1

Related to Cash Damages

  • Direct Damages Each of the Parties shall be liable to the other for any direct damages arising out of or relating to its performance or failure to perform under this Agreement.

  • Actual Damages Contractor is liable to CMHA for all actual and direct damages caused by Contractor’s default. In the event Contractor fails to provide services or material as provided for in the Contract Documents, CMHA may substitute the services and/or material from a third party. CMHA may recover the costs associated with acquiring substitute services and/or materials, less any expense or costs saved by Contractor’s default, from Contractor.

  • Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.

  • Punitive Damages The Administrative Agent, the Lenders and the Borrower hereby agree that no such Person shall have a remedy of punitive or exemplary damages against any other party to a Loan Document and each such Person hereby waives any right or claim to punitive or exemplary damages that they may now have or may arise in the future in connection with any Dispute, whether such Dispute is resolved through arbitration or judicially.

  • Indirect Damages To the maximum extent permitted by Law, the Stripe Parties will not be liable to you or your Affiliates in relation to this Agreement or the Services during and after the Term (whether in contract, negligence, strict liability or tort, or on other legal or equitable grounds) for any lost profits, personal injury, property damage, loss of data, business interruption, indirect, incidental, consequential, exemplary, special, reliance, or punitive damages, even if these losses, damages, or costs are foreseeable, and whether or not you or the Stripe Parties have been advised of their possibility.

  • Special Damages NOTWITHSTANDING ANY OTHER PROVISION OF THIS AGREEMENT TO THE CONTRARY, AND EXCEPT AS PROVIDED BELOW, IN NO EVENT WILL EITHER PARTY OR ANY PERSON IN ITS GROUP BE LIABLE FOR SPECIAL, INCIDENTAL, INDIRECT, COLLATERAL, CONSEQUENTIAL OR PUNITIVE DAMAGES OR LOST PROFITS SUFFERED BY AN INDEMNITEE, HOWEVER CAUSED AND ON ANY THEORY OF LIABILITY, IN CONNECTION WITH ANY DAMAGES ARISING HEREUNDER OR THEREUNDER; PROVIDED, HOWEVER, THAT TO THE EXTENT AN INDEMNIFIED PARTY IS REQUIRED TO PAY ANY DAMAGES, INCLUDING SPECIAL, INCIDENTAL, INDIRECT, COLLATERAL, CONSEQUENTIAL OR PUNITIVE DAMAGES OR LOST PROFITS (OTHER THAN DAMAGES OR LOST PROFITS CONSTITUTING EXCLUDED LIABILITIES), TO A PERSON WHO IS NOT IN EITHER GROUP IN CONNECTION WITH A THIRD PARTY CLAIM, SUCH DAMAGES WILL CONSTITUTE DIRECT DAMAGES AND WILL NOT BE SUBJECT TO THE LIMITATION SET FORTH IN THIS SECTION 11.17.

  • Monetary Damages In the event that the Partnership breaches its obligations set forth in Article 2, Article 3, or Article 6 with respect to a Protected Partner the Protected Partner’s sole right shall be to receive from the Partnership, and the Partnership shall pay to such Protected Partner as damages, an amount equal to:

  • Termination Damages If the Term of this Lease is terminated for default, unless and until Landlord elects lump sum liquidated damages described in the next paragraph, Tenant covenants, as an additional, cumulative obligation after any such termination, to pay punctually to Landlord all the sums and perform all of its obligations in the same manner as if the Term had not been terminated. In calculating such amounts Tenant will be credited with the net proceeds of any rent then actually received by Landlord from a reletting of the Premises after deducting all Rent that has not then been paid by Tenant, provided that Tenant shall never be entitled to receive any portion of the re-letting proceeds, even if the same exceed the Rent originally due hereunder.

  • Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.

  • No Punitive Damages Each party agrees that it shall not have a remedy of punitive or exemplary damages against the other in any Dispute and hereby waives any right or claim to punitive or exemplary damages it may have now or which may arise in the future in connection with any Dispute, whether the Dispute is resolved by arbitration or judicially.

Time is Money Join Law Insider Premium to draft better contracts faster.