Commencement Date. The Subcontractor shall be permitted to begin the Services on , 20 (“Commencement Date”).
Commencement Date. 3.1 This Licence will commence on the 1st day of 20 . (“Commencement Date”)
Commencement Date. The effective date of an Interconnection Service Agreement shall be the date provided in Section 4.0 of the Interconnection Service Agreement. Interconnection Service under this Interconnection Service Agreement shall commence upon the satisfaction of the conditions precedent set forth in Section 1.2 below.
Commencement Date. The Commencement Date of this Lease shall be the later of (a) December 1, 2021, and (b) the date upon which occurs the Substantial Completion of the Base Building Work (subject to the penultimate sentence of this paragraph below) and Landlord’s Work in accordance with Law. If the Substantial Completion of the Base Building Representations and Landlord’s Work is delayed by Tenant Delays, then the Commencement Date shall be the date the Landlord’s Work and Base Building Representations would have been Substantially Completed, as reasonably estimated by Landlord, without the Tenant Delays. Notwithstanding anything to the contrary contained herein, Landlord represents to Tenant that on the Commencement Date and as part of the Base Building Work at Landlord’s cost (and not part of Landlord’s Cap) (i) the Demised Premises and Building Structure will be structurally sound and free from leaks, and the Demised Premises will be demised, broom clean, and in compliance with Law, (ii) the Demised Premises will be free from asbestos and other Hazardous Materials in violation of existing Law, (iii) there will be a valid temporary or permanent Certificate of Occupancy permitting the Permitted Use, (iv) the Common Areas will be in good working order, and (v) the Building Systems serving the Demised Premises will be in good working order (items (i) – (v) above being hereinafter referred to as the “Base Building Representations”) , with the following modifications to the Building’s HVAC system: the boiler providing heat to the Building will be replaced; the 30 ton RTU providing cooling to the atrium will be replaced; the building management system (BMS) will be upgraded; the filters on the nine heat pumps serving the Demised Premises will be upgraded from MERV-8 to MERV-13 as and where reasonably able, and any heat pumps in the Demised Premises found not to be functioning will be repaired or replaced; two of the three cooling towers will be retrofitted with new water treatment systems (two have been retrofitted already) (items (i) – (v) above, including the above modifications to the Building’s HVAC system, collectively, the “Base Building Work”). Notwithstanding the foregoing, the Commencement Date shall occur once the Landlord’s Work is Substantially Completed even though the Base Building Work is not Substantially Completed as long as the Base Building Representations are true on the Commencement Date and Landlord has commenced the Base Building Work and is working di...
Commencement Date. The term of this Lease shall commence on the date this Lease is executed (the "Commencement Date") and shall end ten (10) years from the date the payment of rent commences as set forth in Section 4.1 of this Lease, unless sooner terminated pursuant hereto (the "TERM"). Promptly following the Commencement Date, Landlord and Tenant shall confirm the Commencement Date and the expiration date by executing and delivering a Memorandum of Commencement Date ("MEMORANDUM") in the form attached hereto as Exhibit "B." This Lease shall not be void, voidable or subject to termination, nor shall Landlord be liable to Tenant for any loss or damage, resulting from Landlord's inability to deliver the Premises to Tenant on the date specified in Landlord's notice given pursuant to Section 3.2, but no rent hereunder shall be payable hereunder with respect to any delay in delivery of the Premises which is caused solely by Landlord. Provided Tenant has not been in default during the Term of the Lease, Landlord hereby grants Tenant the right to renew the Lease for one (1) additional five (5) year period, at the greater of the then current Basic Rent increased in accordance with this Lease or at the then current fair market lease rental rate for the Building as determined by the Landlord. In order to exercise its renewal option, Tenant shall give Landlord a minimum of six (6) months written notice prior to the end of the Term of its intention to renew this Lease.
Commencement Date. The date on which Interconnection Service commences in accordance with an Interconnection Service Agreement.
Commencement Date. The Commencement Date for each item of new on-order or used on-order Equipment will be the install date as confirmed in writing by Lessee as set forth on the vendor invoice of which a facsimile transmission will constitute an original document. The Commencement Date for sale-leaseback Equipment shall be the date Lessor tenders the purchase price. The Commencement Date for 800 Number Equipment shall be fifteen (15) days from the ship date, such ship date to be set forth on the vendor invoice or if unavailable on the vendor invoice the ship date will be determined by Lessor upon other supporting shipping documentation. Lessor will summarize all approved invoices, purchase documentation and evidence of delivery, as applicable, received in the same calendar month into a Summary Equipment Schedule in the form attached to this Schedule as Exhibit 1, and the Initial Term will begin the first day of the calendar month thereafter. Each Summary Equipment Schedule will contain the Equipment location, description, serial number(s) and cost and will incorporate the terms and conditions of the Master Lease and this Schedule and will constitute a separate lease.
Commencement Date. The term of this Lease ("Lease Term") shall be for twelve (12) years beginning on the earlier of (i) the date a Certificate of Occupancy first is issued affecting the Building, or (ii) the date on which Lessee first occupies or conducts business at the Premises (the "Commencement Date") provided that, (i) for each day of delay by Lessee in failing to approve the interior schematic drawings or the Working Drawings when required under Section 2.04(d), or (ii) for each day of delay by Lessee in failing to approve the Budget, in writing, within fourteen (14) days after delivery by the General Contractor as provided in Section 2.04(d), or (iii) for each day of delay caused by any changes to the approved Working Drawings requested by Lessee, or (iv) for each day that any other act or omission by Lessee causes the construction schedule for Tenant Improvements to be delayed (collectively "Lessee Delay"), the Commencement Date shall occur one (1) day in advance of the date of the Certificate of Occupancy for each such day of delay. For example, if seven (7) days of Lessee Delay causes the date of issuance of the Certificate of Occupancy to occur on July 8, 2001 rather than July 1, 2001, the Commencement Date shall be July 1, 2001 for all purposes, including payment of Base Rent. The Lease Term shall expire, unless sooner terminated or extended as provided herein, on the date which completes twelve (12) years after the Commencement Date occurs, e.g. if the date on which the Commencement Date occurs is July 1, 2001, the Lease Term shall expire on June 30, 2013 and if the Commencement Date is July 3, 2001, the Lease Term shall expire on July 2, 2013 ("Expiration Date"). The parties shall execute a "Memorandum of Commencement of Lease Term" when the Commencement Date becomes known, which shall include a certification of the actual Rentable Area of the Building determined by the methodology described in Section 2.01. and the actual monthly installments of Base Rent to be paid pursuant to Section 4.01., and shall be substantially in the form attached hereto as Exhibit "E."
Commencement Date. The Commencement Date of this Lease shall be the first day of the Term determined in accordance with Paragraph 4.A.
Commencement Date. (3) Subject to the approval by the Minister or determination by arbitration or by consulting engineers as herein provided of each and every of the detailed proposals and matters referred to in clause 5(1) hereof (except if and as modified by the application of clause 6(4) hereof) the date upon which the last of those proposals of the Company shall have been so approved or determined shall be the commencement date for the purposes of this Agreement.
