Liquidated Damages Sample Clauses

Liquidated Damages. The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
AutoNDA by SimpleDocs
Liquidated Damages. The Contractor acknowledges that delayed performance will damage the DepartmentCustomer, but by their nature such damages are difficult to ascertain. Accordingly, the liquidated damages provisions stated in the Contract documents will apply. Liquidated damages are not intended to be a penalty and are solely intended to compensate for damages.
Liquidated Damages. If (i) any Registration Statement required by this Agreement is not filed with the Commission on or prior to the applicable Filing Deadline, (ii) any such Registration Statement has not been declared effective by the Commission on or prior to the applicable Effectiveness Deadline, (iii) any Exchange Offer has not been Consummated on or prior to the Consummation Deadline or (iv) any Registration Statement required by this Agreement is filed and declared effective but shall thereafter (and before the second anniversary of the initial sale) cease to be effective or fail to be usable in connection with resales of the Transfer Restricted Securities without being succeeded immediately by a post-effective amendment to such Registration Statement that cures such failure and that is itself immediately declared effective, and only for such time of non-effectiveness or non-usability (each such event referred to in clauses (i) through (iv), a “Registration Default”), then the Company hereby agrees to pay (and the Guarantors agree to guarantee such payments) liquidated damages to each Holder of Transfer Restricted Securities affected thereby for the first 90-day period immediately following the occurrence of such Registration Default, in an amount equal to $0.05 per week per $1,000 in principal amount of Transfer Restricted Securities held by such Holder for each week or portion thereof that the Registration Default continues. The amount of the liquidated damages shall increase by an additional $0.05 per week per $1,000 in principal amount of Transfer Restricted Securities with respect to each subsequent 90-day period until all Registration Defaults have been cured, the Transfer Restricted Securities become freely tradable without registration under the Securities Act or no Transfer Restricted Securities are outstanding, up to a maximum amount of liquidated damages of $0.25 per week per $1,000 in principal amount of Transfer Restricted Securities; provided that the Company shall in no event be required to pay liquidated damages for more than one Registration Default at any given time. All accrued liquidated damages shall be paid to the Holders entitled thereto, in the manner provided for the payment of interest, on each Interest Payment Date, as more fully set forth in the Indenture and the Notes. Notwithstanding anything to the contrary set forth herein, (1) upon filing of an Exchange Offer Registration Statement with respect to the Transfer Restricted Securities (and...
Liquidated Damages. The Contractor will promptly notify the Department or the Customer upon becoming aware of any circumstances that may reasonably be expected to jeopardize the timely and successful completion (or delivery) of any commodity or contractual service. The Contractor will use commercially reasonable efforts to avoid or minimize any delays in performance and will inform the Department or the Customer of the steps the Contractor is taking or will take to do so, and the projected actual completion (or delivery) time. If the Contractor believes a delay in performance by the Department or the Customer has caused or will cause the Contractor to be unable to perform its obligations on time, the Contractor will promptly so notify the Department and use commercially reasonable efforts to perform its obligations on time notwithstanding the Department’s delay. The Contractor acknowledges that untimely performance or other material noncompliance will damage the Department, but by their nature such damages are difficult to ascertain. Accordingly, the liquidated damages provisions stated in the Contract documents will apply. Liquidated damages are not intended to be a penalty and are solely intended to compensate for damages.
Liquidated Damages. The Company and the Investor hereto acknowledge and agree that the sums payable under subsection 2(c) above shall constitute liquidated damages and not penalties and are in addition to all other rights of the Investor, including the right to call a default. The parties further acknowledge that (i) the amount of loss or damages likely to be incurred is incapable or is difficult to precisely estimate, (ii) the amounts specified in such subsections bear a reasonable relationship to, and are not plainly or grossly disproportionate to, the probable loss likely to be incurred in connection with any failure by the Company to obtain or maintain the effectiveness of a Registration Statement, (iii) one of the reasons for the Company and the Investor reaching an agreement as to such amounts was the uncertainty and cost of litigation regarding the question of actual damages, and (iv) the Company and the Investor are sophisticated business parties and have been represented by sophisticated and able legal counsel and negotiated this Agreement at arm's length.
Liquidated Damages. The actual damages to the Developer, in the event the Connecting Transmission Owner’s Attachment Facilities or System Upgrade Facilities or System Deliverability Upgrades are not completed by the dates designated by the Developer and accepted by the Connecting Transmission Owner pursuant to subparagraphs 5.1.2 or 5.1.4, above, may include Developer’s fixed operation and maintenance costs and lost opportunity costs. Such actual damages are uncertain and impossible to determine at this time. Because of such uncertainty, any liquidated damages paid by the Connecting Transmission Owner to the Developer in the event that Connecting Transmission Owner does not complete any portion of the Connecting Transmission Owner’s Attachment Facilities, System Upgrade Facilities or System Deliverability Upgrades by the applicable dates, shall be an amount equal to 1/2 of 1 percent per day of the actual cost of the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades, in the aggregate, for which Connecting Transmission Owner has assumed responsibility to design, procure and construct. However, in no event shall the total liquidated damages exceed 20 percent of the actual cost of the Connecting Transmission Owner Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades for which the Connecting Transmission Owner has assumed responsibility to design, procure, and construct. The foregoing payments will be made by the Connecting Transmission Owner to the Developer as just compensation for the damages caused to the Developer, which actual damages are uncertain and impossible to determine at this time, and as reasonable liquidated damages, but not as a penalty or a method to secure performance of this Agreement. Liquidated damages, when the Developer and Connecting Transmission Owner agree to them, are the exclusive remedy for the Connecting Transmission Owner’s failure to meet its schedule. Further, Connecting Transmission Owner shall not pay liquidated damages to Developer if: (1) Developer is not ready to commence use of the Connecting Transmission Owner’s Attachment Facilities or System Upgrade Facilities or System Deliverability Upgrades to take the delivery of power for the Developer’s Large Generating Facility’s Trial Operation or to export power from the Developer’s Large Generating Facility on the specified dates, unless the Developer would have been able to commence use of the...
Liquidated Damages. The actual damages to the Interconnection Customer, in the event the Participating TO's Interconnection Facilities or Network Upgrades are not completed by the dates designated by the Interconnection Customer and accepted by the Participating TO pursuant to subparagraphs 5.1.2 or 5.1.4, above, may include Interconnection Customer’s fixed operation and maintenance costs and lost opportunity costs. Such actual damages are uncertain and impossible to determine at this time. Because of such uncertainty, any liquidated damages paid by the Participating TO to the Interconnection Customer in the event that the Participating TO does not complete any portion of the Participating TO's Interconnection Facilities or Network Upgrades by the applicable dates, shall be an amount equal to ½ of 1 percent per day of the actual cost of the Participating TO's Interconnection Facilities and Network Upgrades, in the aggregate, for which the Participating TO has assumed responsibility to design, procure and construct. However, in no event shall the total liquidated damages exceed 20 percent of the actual cost of the Participating TO’s Interconnection Facilities and Network Upgrades for which the Participating TO has assumed responsibility to design, procure, and construct. The foregoing payments will be made by the Participating TO to the Interconnection Customer as just compensation for the damages caused to the Interconnection Customer, which actual damages are uncertain and impossible to determine at this time, and as reasonable liquidated damages, but not as a penalty or a method to secure performance of this LGIA. Liquidated damages, when the Parties agree to them, are the exclusive remedy for the Participating TO’s failure to meet its schedule. No liquidated damages shall be paid to the Interconnection Customer if: (1) the Interconnection Customer is not ready to commence use of the Participating TO's Interconnection Facilities or Network Upgrades to take the delivery of power for the Electric Generating Unit's Trial Operation or to export power from the Electric Generating Unit on the specified dates, unless the Interconnection Customer would have been able to commence use of the Participating TO's Interconnection Facilities or Network Upgrades to take the delivery of power for Electric Generating Unit's Trial Operation or to export power from the Electric Generating Unit, but for the Participating TO’s delay; (2) the Participating TO’s failure to meet the specified dates...
AutoNDA by SimpleDocs
Liquidated Damages. THE PARTIES HAVE DISCUSSED AND NEGOTIATED IN GOOD FAITH THE QUESTION OF THE DAMAGES THAT WOULD BE SUFFERED BY SELLER IF THE CLOSING DOES NOT OCCUR BECAUSE BUYER BREACHES THIS AGREEMENT AND HAVE ENDEAVORED TO REASONABLY ESTIMATE SUCH DAMAGES. THEY AGREE THAT (I) SUCH DAMAGES ARE AND WILL BE IMPRACTICABLE OR EXTREMELY DIFFICULT TO FIX, (II) LIQUIDATED DAMAGES IN THE AMOUNT OF THE DEPOSIT (AS IT MAY BE INCREASED FROM TIME TO TIME) ARE AND WOULD BE REASONABLE AS A MEASURE OF SUCH DAMAGES, (III) IN THE EVENT OF SUCH BREACH, SELLER SHALL BE ENTITLED TO RETAIN THE DEPOSIT AS SUCH LIQUIDATED DAMAGES, AND (IV) IN CONSIDERATION OF THE PAYMENT OF SUCH LIQUIDATED DAMAGES, SELLER SHALL BE DEEMED TO HAVE WAIVED ALL OTHER CLAIMS FOR DAMAGES OR RELIEF AT LAW OR IN EQUITY ON ACCOUNT OF THE FAILURE OF THE CLOSING TO OCCUR, EXCEPT FOR: (A) CLAIMS FOR THE RETURN OR OTHER DELIVERY OF DOCUMENTS IN CONNECTION WITH THIS AGREEMENT; (B) ACTIONS TO EXPUNGE A LIS PENDENS OR OTHER CLOUDS ON TITLE CAUSED BY BUYER; (C) CLAIMS ON ACCOUNT OF BUYER'S INDEMNITY OBLIGATIONS UNDER THIS AGREEMENT, AND (D) ATTORNEYS' FEES AND COSTS INCURRED BY SELLER INCIDENT TO CLAUSES (A) THROUGH (C). NOTWITHSTANDING THE FOREGOING, IN THE EVENT BUYER OBJECTS TO, FAILS TO COOPERATE WITH OR OTHERWISE OPPOSES SELLER'S WITHDRAWAL OF THE DEPOSIT OUT OF THE ESCROW, SELLER SHALL HAVE ALL OF THE REMEDIES OTHERWISE AVAILABLE TO SELLER AT LAW OR IN EQUITY. SELLER'S INITIALS BUYER'S INITIALS __________ __________
Liquidated Damages. In light of the difficulties in estimating the damages for an early termination of Executive’s employment under this Agreement, Company and Executive hereby agree that the payments, if any, to be received by Executive pursuant to this Article 5 shall be received by Executive as liquidated damages.
Liquidated Damages. Unnecessary damage to or negligent or willful cutting of undesignated timber, as described in B3.45, on portions of Sale Area cut over under this contract is likely to cause substantial silvicultural or other damage to the National Forest. It will be difficult, if not impossible, to determine the amount of such damage. Therefore, Purchaser shall pay as fixed, agreed, and liquidated damages an amount equivalent to the amount payable at Current Contract Rates. If designated by Contracting Officer, Purchaser shall remove such damaged or cut timber and pay for it at Current Contract Rates.
Time is Money Join Law Insider Premium to draft better contracts faster.