DELIVERY. 5.1 – Unless there is agreement to the contrary, the supplies shall be deemed to be goods supplied ex works, without packing.
DELIVERY. 3.1 The delivery of the Products shall be made by MUNTERS ITALY S.P.A. to the Seller’s site in accordance with Incoterms of the International Chamber of Commerce, as in force at the date of the execution of the Agreement within the delivery time specified in the Agreement.
DELIVERY. 6.1 Delivery shall be effected as agreed in the contract. Delivery dates and delivery periods agreed in the contract are only binding if they have been agreed as binding and Buyer has provided Seller in a timely manner with all of the information or documentation required for the performance documentazione richieste per l'esecuzione di tale consegna e l'Acquirente ha effettuato dei pagamenti anticipati secondo le modalità e gli importi convenuti dalle parti. I periodi di consegna convenuti dalle parti inizieranno alla data di conferma dell'ordine. In caso di contratti aggiuntivi o integrativi stipulati a una data successiva, i periodi di consegna e le date di consegna saranno prorogati o riprogrammati di conseguenza, come applicabile.
DELIVERY. 4.1. The delivery terms are those indicated in the order confirmation and usually expressed with indication of the week foreseen for the preparation of the goods.
DELIVERY. Place of delivery
DELIVERY. The seller undertakes to comply with the agreed delivery terms. Events that prevent or delay the shipment of the materials, including but not limited to employee strikes, raw material suppliers’ delay, goods and services that make it extremely difficult or expensive to acquire raw materials or services required for production, events not attributable to the seller, providers’ termination or suspension of the electricity and water supply, injuries in the workplace resulting in the closing of the production spaces, as well as bans on imports, strikes (even company strikes), and other events that prevent or delay production and/or machining are considered force majeure. The seller will not be held liable for delayed deliveries due to force majeure. In the aforementioned cases, the seller may delay the delivery for the entire period from the occurrence of the force majeure to its end without any penalty. The delivery deadline is indicative and is calculated from the moment in which all the elements of the contract have been supplied and irrevocably defined, and provided that the purchaser has paid all instalments in a timely manner. In the event of outstanding payments, even concerning previous supplies, the seller will be entitled to suspend the execution of the contract until the purchaser settles the payments and provides the guarantees for the other instalments. The seller is entitled to making partial deliveries.
DELIVERY. 6.1 Terms of delivery shall be Ex Works, European central warehouse, ECOMAL Kirchzarten, Germany (Incoterms® 2010); delivery of the goods shall be made by the Customer collecting the goods at the Seller’s premises at any time after the Seller has notified the Customer that the goods are ready for collection.
DELIVERY. The delivery times on the confirmation of sale are given in good faith and shall be considered always as only approximate and with reservation customary in the steel industry.
DELIVERY. Product deliveries shall be ex-works Manufacturer's premises (INCOTERMS 2000).
DELIVERY. The goods travel at the customer’s risk, even when sold free to destination. Ac Rolcar S.r.l.’s responsi- bility ceases when the goods leave its warehouse. On receipt of the goods, the customer shall check that: • The number of packages matches that stated on the shipping document or palmtop; • The packaging is intact, and is not damaged, damp, or in any way altered or tampered with, including the seals (packaging tape, etc.). The courier making the delivery shall be immediately informed of any damage or missing packages, adding the wording “collection under reservation for n°. missing and/or damaged packages” to the shipping document or palmtop, and the customer shall inform Ac Rolcar S.r.l. in writing within eight calendar days of delivery. We recommend always putting the Reservation, for protection. The customer’s signing of the shipping document implies the full acceptance of the goods. If the packaging is intact, any claims of defects and apparent non-compliance shall be notified to Ac Rolcar S.r.l. within eight calendar days of delivery.