Work Warranty definition

Work Warranty means the warranties of Contractor under Section 17.1.

Examples of Work Warranty in a sentence

  • Nothing contained in this Article 11 shall establish a period of limitation for any warranty obligation under the Contract Documents (other than the Defective Work Warranty) or modify a statute of limitations or repose.

  • The expiration of the Defective Work Warranty, and expiration of any of Contractor’s other guarantees or obligations to correct Defective Work, shall not relieve Contractor of the obligation to correct, at its own expense, latent defects in the Work.

  • The one (1) year Defective Work Warranty neither limits the time within which Owner may enforce Contractor’s obligation to comply with the Contract Documents, nor the time within which Owner may commence proceedings pertaining to Contractor’s obligations under the Contract Documents.

  • Contractor shall within ten (10) Days after being notified in writing by the County of any defect in the Work or non-conformance of the Work (Warranty Work), commence and prosecute with due diligence all Work necessary to fulfill the terms of the warranty at its sole cost and expense.

  • The [one (1) year] Defective Work Warranty neither limits the time within which Owner may enforce Contractor’s obligation to comply with the Contract Documents, nor the time within which Owner may commence proceedings pertaining to Contractor’s obligations under the Contract Documents.

  • Vendor must provide a detailed Scope of Work, Warranty and Terms & Conditions.

  • Indeed, there is substantial evidence that the Court’s theory – and what we are calling programmatic pol- itics – is an accurate depiction of distributive politics in many democracies.

  • Following the expiration of the Work Warranty Period (and as to any cure Work, following the expiration of the extension of the Work Warranty Period) for a SGF, Owner expressly waives and releases Contractor from all claims, except those previously asserted, relating to defects or deficiencies in the Work with respect to such SGF, whether arising in contract, warranty, tort (including negligence), strict liability, equity or otherwise.

  • If a warranty issue arises on any equipment after the Work Warranty Period, and the equipment has a warranty period that extends beyond the Work Warranty Period, Owner shall contact the manufacturer directly to resolve such warranty issues and Owner acknowledges that the manufacturer shall have sole responsibility for such issues.

  • Section 25A(c) of the Act states the following: (c) Returns Relating to Tuition and Related Expenses (1) In General -- Subpart B of part III of subchapter A of chapter 61 .

Related to Work Warranty

  • Manufacturer’s Warranty means the warranty supplied from time to time by the manufacturer of the Goods as at the date of the acceptance of the Statement of Work; “PPSA” means the Personal Property Securities Xxx 0000; “Price” means the amount specified within each Statement of Work (subject to any Variation) or as otherwise specified from the Company to the Customer representing the cost for the Works; “Related Work” means any additional building, carpentry, painting, plastering, plumbing or other work or other trades that the Customer requires, which are not to be carried out by the Company; “Services” means the services provided by the Company to the Customer as part of the Works, which may include without limitation the installation of Goods; “Services Delay Charge” means the services delay charge (if any) set out in the Statement of Work; “Services Interruption Event” means any interruption to a Works caused by; a Force Majeure Event, the Customer’s failure to carry out or perform any obligation required of it under this agreement which in the sole opinion of the Company does or may cause a delay in the Works and any other matter which in the reasonable opinion of the Company will cause an interruption or delay in the performance of the Works; “Statement of Work” means the details outlining the provision of the Works, which statement can be delivered verbally or in writing (including email) and may include (where applicable) an estimate or quotation (as specifically expressed as the case) of costs; “Variation” means a change in the Statement of Work including the specifications, scope, time of supply, price or scale of the Works and such variation shall form part of this agreement; “Workmanship” means a good and high quality and standard of delivery in connection with the Services performed; “Works” means the supply of Goods and the provision of Services to the Customer as per each Statement of Work;

  • Product Warranty has the meaning set forth in Section 9.3.

  • Limited Warranty means the limited warranties and your coverage provided by IKO for your Shingles as expressly set out in this document, and are the only warranties being provided by IKO.

  • Improvement warranty means an applicant's unconditional warranty that the

  • Extended Warranty means an agreement for a specified duration to

  • Warranty Period /„Maintenance Period‟ shall mean the period during which the Contractor shall remain liable for repair or replacement of any defective part of the Works performed under the Contract.

  • Defects Liability Period (Warranty Period) means the period stated in the Schedule A Special Stipulations, following the taking over, during which the Contractor is responsible for making good defects and damage in accordance with Clause 15.

  • Express warranty means an express warranty as set forth in sections 4-2-313 and 4-2.5-210, C.R.S. An express warranty shall cover every part of a new facilitative device.

  • Warranty means any one of them.

  • Improvement warranty period means a period:

  • Defective Work means (a) Work that is unsatisfactory, deficient or damaged, does not conform to the Contract Documents, or does not meet the requirements of any inspection, test or approval, or (b) Work associated with punch list items that the Contractor fails to complete within a reasonable time after issuance of the punch list by the Project Manager.

  • Tax Warranty means a representation or warranty in Sections 3.17 or 3.19.

  • Seller’s Warranties means Seller’s representations and warranties set forth in Section 9.2 and the Closing Documents executed by Seller, as such representations and warranties may be deemed modified or waived by Buyer pursuant to the terms of this Agreement.

  • technical specification means a document that prescribes technical requirements to be fulfilled by a product, process or service;

  • The Specification means the Specification annexed to or issued with G.T.C.C. and shall include the schedules & drawings attached thereto as well as all samples and pattern, if any.

  • Project Deliverables means the Project deliverables set out in Schedule 2. Project Material means all the material including but not limited to documents, computer software, and data stored by any means which is created by the Fellow in the course of undertaking the Project.

  • Work/ works means work / works to be executed in accordance with the contract.

  • Software Update means a package used to upgrade software to a new version including a change of the configuration parameters.

  • Contract Specifications means the principal trading terms in CFD (for example Spread, Swaps, Lot Size, Initial Margin, Necessary Margin, Hedged Margin, the minimum level for placing Stop Loss, Take Profit and Limit Orders, financing charges, charges etc) for each type of CFD as determined by the Company from time to time.

  • Independent Software Vendor or “ISV” means a Person that makes available to Participants and Authorized Traders a system or platform offering smart order routing, front-end trading applications, an aggregation platform or a combination of the foregoing but that does not provide Participants or Authorized Traders with the ability to effect transactions other than through the Trading System.

  • Standard Software means Software identified as such in Appendix 4 of the Contract Agreement and such other Software as the parties may agree in writing to be Standard Software.

  • Software Release means any subsequent version of Software provided by EMC after initial Delivery of Software, but does not mean a new Product.

  • IS Specification means the Specification of latest edition with amendments, if any, up to time of receipt of tender by Corporation issued by the Bureau of Indian Standards as referred to in the specifications and / or work orders.

  • Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.

  • Contractor Software means software which is proprietary to the Contractor, including software which is or will be used by the Contractor for the purposes of providing the Services.

  • Warranty Xxxx of Sale means the warranty (as to title) xxxx of sale covering the Aircraft executed by Manufacturer or an affiliate of Manufacturer in favor of Company and specifically referring to each Engine, as well as the Airframe, constituting a part of the Aircraft.