{"component": "definition", "props": {"groups": [{"samples": [{"hash": "f1XWmWe2xka", "uri": "/contracts/f1XWmWe2xka#work-progress-schedule", "label": "Grant Agreement", "score": 35.5808830261, "published": true}, {"hash": "y3co7bHeQl", "uri": "/contracts/y3co7bHeQl#work-progress-schedule", "label": "Grant Agreement", "score": 35.3142623901, "published": true}, {"hash": "dmn1Ca496Tf", "uri": "/contracts/dmn1Ca496Tf#work-progress-schedule", "label": "General Construction Services Contract", "score": 35.2904891968, "published": true}], "snippet": "means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.", "size": 70, "snippet_links": [{"key": "time-schedule", "type": "definition", "offset": [30, 43]}, {"key": "by-contractor", "type": "clause", "offset": [67, 80]}, {"key": "as-required-by", "type": "clause", "offset": [143, 157]}, {"key": "the-work-and-the-project", "type": "clause", "offset": [176, 200]}, {"key": "baseline-schedule", "type": "definition", "offset": [247, 264]}], "hash": "75b583afb03b302169d8cceb354f45ef", "id": 1}, {"samples": [{"hash": "b1teob2CuGa", "uri": "https://finance.untsystem.edu/sites/default/files/bid-documents/rfq769-25-1001aw-idiq-landscape_architectural_services.pdf", "label": "Notice", "score": 24.1418479817, "published": false}, {"hash": "d3IKQyfzpA3", "uri": "https://finance.untsystem.edu/sites/default/files/bid-documents/rfq769-25-991aw-idiq-geotechnical_engineering_and_construction_materials_testing_services.pdf", "label": "Notice", "score": 23.0258655548, "published": false}, {"hash": "3UG8NY3LTVh", "uri": "https://finance.untsystem.edu/sites/default/files/bid-documents/rfq769_25_995cs_pohl_rec_center.pdf", "label": "Notice", "score": 22.780122757, "published": false}], "snippet": "means the continually updated time schedule prepared and monitored by Contractor that coordinates and integrates activities of the Project, including Contractor\u2019s services, Design Professional\u2019s services, the work of other consultants, suppliers, and Owner\u2019s activities with the anticipated construction schedules for other contractors. The Work Progress Schedule accurately indicates all necessary and appropriate revisions, including a Longest Path impact analysis, as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.", "size": 52, "snippet_links": [{"key": "time-schedule", "type": "definition", "offset": [30, 43]}, {"key": "by-contractor", "type": "clause", "offset": [67, 80]}, {"key": "activities-of-the-project", "type": "clause", "offset": [113, 138]}, {"key": "design-professional", "type": "definition", "offset": [173, 192]}, {"key": "other-consultants", "type": "clause", "offset": [217, 234]}, {"key": "construction-schedules", "type": "clause", "offset": [291, 313]}, {"key": "other-contractors", "type": "definition", "offset": [318, 335]}, {"key": "the-work-progress-schedule", "type": "clause", "offset": [337, 363]}, {"key": "necessary-and-appropriate", "type": "definition", "offset": [389, 414]}, {"key": "longest-path", "type": "definition", "offset": [438, 450]}, {"key": "impact-analysis", "type": "clause", "offset": [451, 466]}, {"key": "as-required-by", "type": "clause", "offset": [468, 482]}, {"key": "the-work-and-the-project", "type": "clause", "offset": [501, 525]}, {"key": "baseline-schedule", "type": "definition", "offset": [572, 589]}], "hash": "616d4e87e098f89089f442eae6711c28", "id": 2}, {"samples": [{"hash": "9IiJGMizGWB", "uri": "/contracts/9IiJGMizGWB#work-progress-schedule", "label": "Design Build Services Agreement", "score": 34.6539878845, "published": true}, {"hash": "5UJfn6ViUSG", "uri": "/contracts/5UJfn6ViUSG#work-progress-schedule", "label": "Construction Management Agreement", "score": 33.1977081299, "published": true}, {"hash": "54OJjbXyUOC", "uri": "/contracts/54OJjbXyUOC#work-progress-schedule", "label": "Construction Management Agreement", "score": 33.1210632324, "published": true}], "snippet": "or \u201cWPS\u201d shall have the meaning given in Paragraph 5.3.1.", "size": 51, "snippet_links": [], "hash": "22cfc6f2400a7c851deb410add45e9c3", "id": 3}, {"samples": [{"hash": "ku2CaHWIIW3", "uri": "/contracts/ku2CaHWIIW3#work-progress-schedule", "label": "Indefinite Delivery Indefinite Quantity Professional Services Agreement", "score": 33.2442436218, "published": true}, {"hash": "ggj0oHXHoyy", "uri": "/contracts/ggj0oHXHoyy#work-progress-schedule", "label": "Professional Services Agreement", "score": 33.126537323, "published": true}, {"hash": "fEe02oBsV6x", "uri": "/contracts/fEe02oBsV6x#work-progress-schedule", "label": "Professional Engineering Services Agreement", "score": 33.1046409607, "published": true}], "snippet": "has the same meaning as defined in UGC Section 1.49.", "size": 43, "snippet_links": [{"key": "same-meaning", "type": "clause", "offset": [8, 20]}], "hash": "daa13e8901e7a874f8e3683c6056ec54", "id": 4}, {"samples": [{"hash": "98Gfg6ZHUSS", "uri": "/contracts/98Gfg6ZHUSS#work-progress-schedule", "label": "Construction Manager at Risk Agreement", "score": 33.1484375, "published": true}, {"hash": "ekGTzn8dpJx", "uri": "/contracts/ekGTzn8dpJx#work-progress-schedule", "label": "Construction Manager at Risk Agreement", "score": 30.4723072052, "published": true}, {"hash": "hHrN2TgVdBC", "uri": "/contracts/hHrN2TgVdBC#work-progress-schedule", "label": "Construction Manager at Risk Agreement", "score": 28.163690567, "published": true}], "snippet": "means the schedule prepared and maintained in accordance with the Critical Path Method and the requirements of the Special Conditions, if any, and the UGC, for design and construction of the Project, reflecting the CMR\u2019s actual progress of the construction of the Work and the scheduled activities and current plans for completing the Work. The Work Progress Schedule may subsequently modified by mutual agreement between TFC and CMR to reflect any refinement in its requirements.", "size": 8, "snippet_links": [{"key": "the-schedule", "type": "clause", "offset": [6, 18]}, {"key": "in-accordance-with", "type": "definition", "offset": [43, 61]}, {"key": "critical-path-method", "type": "definition", "offset": [66, 86]}, {"key": "the-special-conditions", "type": "clause", "offset": [111, 133]}, {"key": "design-and-construction-of-the-project", "type": "clause", "offset": [160, 198]}, {"key": "work-and", "type": "clause", "offset": [264, 272]}, {"key": "scheduled-activities", "type": "clause", "offset": [277, 297]}, {"key": "current-plans", "type": "clause", "offset": [302, 315]}, {"key": "completing-the-work", "type": "clause", "offset": [320, 339]}, {"key": "the-work-progress-schedule", "type": "clause", "offset": [341, 367]}, {"key": "agreement-between", "type": "clause", "offset": [404, 421]}], "hash": "39ee82b29284a6d1b9584c13ca68b23d", "id": 5}, {"samples": [{"hash": "cQpI3rcUmaZ", "uri": "/contracts/cQpI3rcUmaZ#work-progress-schedule", "label": "Construction Contract", "score": 31.0800037384, "published": true}, {"hash": "b4e6FX31nU8", "uri": "/contracts/b4e6FX31nU8#work-progress-schedule", "label": "Construction Contract", "score": 31.0800037384, "published": true}, {"hash": "1N2P7DuUDPC", "uri": "/contracts/1N2P7DuUDPC#work-progress-schedule", "label": "Construction Contract", "score": 31.0800037384, "published": true}], "snippet": "means the CPM Schedule prepared and maintained in accordance with the Critical Path Method and the requirements of the Agreement, the Special Conditions (if any), and the UGC, reflecting the Contractor\u2019s actual progress of the construction of the Work and the scheduled activities and current plans for completing the Work and updated as required in Paragraph 7.3.", "size": 7, "snippet_links": [{"key": "cpm-schedule", "type": "clause", "offset": [10, 22]}, {"key": "in-accordance-with", "type": "definition", "offset": [47, 65]}, {"key": "critical-path-method", "type": "definition", "offset": [70, 90]}, {"key": "the-agreement", "type": "clause", "offset": [115, 128]}, {"key": "the-special-conditions", "type": "clause", "offset": [130, 152]}, {"key": "the-contractor", "type": "clause", "offset": [187, 201]}, {"key": "work-and", "type": "clause", "offset": [247, 255]}, {"key": "scheduled-activities", "type": "clause", "offset": [260, 280]}, {"key": "current-plans", "type": "clause", "offset": [285, 298]}, {"key": "completing-the-work", "type": "clause", "offset": [303, 322]}, {"key": "as-required", "type": "clause", "offset": [335, 346]}], "hash": "382e6feeddd5b84649fe8c0adc8e9388", "id": 6}, {"samples": [{"hash": "7k3ep3aWlKG", "uri": "/contracts/7k3ep3aWlKG#work-progress-schedule", "label": "Engineering, Procurement and Construction Agreement (Public Service Co of New Mexico)", "score": 21.0, "published": true}, {"hash": "4tCqxmXYr8y", "uri": "/contracts/4tCqxmXYr8y#work-progress-schedule", "label": "Engineering, Procurement and Construction Agreement (PNM Resources Inc)", "score": 21.0, "published": true}], "snippet": "means the timeline for completion of each principal category of the Work for achieving Substantial Completion of the Facility by the Contract Completion Date. The Work Progress Schedule is attached hereto as Exhibit B.", "size": 4, "snippet_links": [{"key": "timeline-for-completion", "type": "clause", "offset": [10, 33]}, {"key": "each-principal", "type": "definition", "offset": [37, 51]}, {"key": "work-for", "type": "definition", "offset": [68, 76]}, {"key": "substantial-completion-of-the-facility", "type": "definition", "offset": [87, 125]}, {"key": "contract-completion-date", "type": "clause", "offset": [133, 157]}, {"key": "the-work-progress-schedule", "type": "clause", "offset": [159, 185]}, {"key": "attached-hereto-as-exhibit", "type": "definition", "offset": [189, 215]}], "hash": "310bd502c266df143bed4da4a8356cbe", "id": 7}, {"samples": [{"hash": "d8P5C8NRHuC", "uri": "/contracts/d8P5C8NRHuC#work-progress-schedule", "label": "Loan Agreement (Emeritus Corp\\wa\\)", "score": 18.0, "published": true}], "snippet": "means the schedule for the Completion of the Work and parts thereof, as reasonably approved by Lender in writing. The Work Progress Schedule shall be attached hereto as Exhibit E at such time as it has been prepared by Borrower and reasonably approved by Lender in writing.", "size": 2, "snippet_links": [{"key": "the-schedule", "type": "clause", "offset": [6, 18]}, {"key": "work-and", "type": "clause", "offset": [45, 53]}, {"key": "by-lender", "type": "clause", "offset": [92, 101]}, {"key": "in-writing", "type": "clause", "offset": [102, 112]}, {"key": "the-work-progress-schedule", "type": "clause", "offset": [114, 140]}, {"key": "exhibit-e", "type": "definition", "offset": [169, 178]}, {"key": "by-borrower", "type": "clause", "offset": [216, 227]}], "hash": "312137549ad3e64d49e4896c63b6a2aa", "id": 8}, {"samples": [{"hash": "2ZpOccHfTlH", "uri": "/contracts/2ZpOccHfTlH#work-progress-schedule", "label": "Construction Services Contract", "score": 23.4859676361, "published": true}], "snippet": "has the same meaning as defined in UGC, Section 1.46 that sets out the critical path and deadlines for completion of discrete portions of the progress of construction of the Project beginning with Pre-Construction Phase and ending with final and unconditional acceptance by TFC.", "size": 1, "snippet_links": [{"key": "same-meaning", "type": "clause", "offset": [8, 20]}, {"key": "critical-path", "type": "clause", "offset": [71, 84]}, {"key": "completion-of", "type": "clause", "offset": [103, 116]}, {"key": "construction-of-the-project", "type": "definition", "offset": [154, 181]}, {"key": "beginning-with", "type": "clause", "offset": [182, 196]}, {"key": "construction-phase", "type": "clause", "offset": [201, 219]}, {"key": "acceptance-by", "type": "clause", "offset": [260, 273]}], "hash": "5b4befa8953414ce874aaa22a445fcc7", "id": 9}, {"samples": [{"hash": "1Msu8t7BXm6", "uri": "/contracts/1Msu8t7BXm6#work-progress-schedule", "label": "Development and Receivables Loan and Security Agreement (Signature Resorts Inc)", "score": 18.0, "published": true}], "snippet": "the schedule for the Completion of the Work and parts thereof, as approved by Lender in writing. The Work Progress Schedule approved by Lender on the date hereof is attached as Exhibit 0.", "size": 1, "snippet_links": [{"key": "the-schedule", "type": "clause", "offset": [0, 12]}, {"key": "work-and", "type": "clause", "offset": [39, 47]}, {"key": "by-lender", "type": "clause", "offset": [75, 84]}, {"key": "in-writing", "type": "clause", "offset": [85, 95]}, {"key": "the-work-progress-schedule", "type": "clause", "offset": [97, 123]}, {"key": "date-hereof", "type": "clause", "offset": [150, 161]}], "hash": "5462d6fd1d32b8e1db807f81dac8f3d1", "id": 10}], "next_curs": "CmMSXWoVc35sYXdpbnNpZGVyY29udHJhY3Rzcj8LEhpEZWZpbml0aW9uU25pcHBldEdyb3VwX3Y1NiIfd29yay1wcm9ncmVzcy1zY2hlZHVsZSMwMDAwMDAwYQyiAQJlbhgAIAA=", "definition": {"snippet": "means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.", "size": 237, "title": "Work Progress Schedule", "id": "work-progress-schedule", "examples": ["Contractor\u2019s submittal schedule must be consistent with the <strong>Work Progress Schedule</strong> and identify critical submittals.", "The Owner has no duty to make progress payments unless accompanied by the updated <strong>Work Progress Schedule</strong>.", "The Contractor shall submit an electronic and a paper copy of the initial <strong>Work Progress Schedule</strong> reflecting accurate and reliable representations of the planned progress of the Work, the Work to date if any, and of the Contractor\u2019s actual plans for its completion.", "Refer to requirements for the <strong>Work Progress Schedule</strong> for inclusion of procurement activities therein.", "Contractor may revise the <strong>Work Progress Schedule</strong> when in Contractor\u2019s judgment it becomes necessary for the management of the Work.", "The Contractor shall include an estimate as to the date of scheduled progress recovery and an updated <strong>Work Progress Schedule</strong> illustrating the Contractor&#x27;s plan for achieving timely completion of the Project.", "The Contractor shall provide with each time extension request a quantitative demonstration of the impact of the delay on Project completion time, based on the <strong>Work Progress Schedule</strong>.", "Regardless, the Submittal Register shall identify dates submitted and returned andshall be used to confirm status and disposition of particular items submitted, including approval or other action taken and other information not conveniently tracked through the <strong>Work Progress Schedule</strong>.", "The Contractor shall update the <strong>Work Progress Schedule</strong> and the Submittal Register monthly, as a minimum, to reflect progress to date and current plans for completing the Work, and submit a paper and electronic copy of the update to the A/E and ODR as directed but as a minimum with each request for payment.", "The Contractor is responsible for providing Samples of sufficient size for test purposes and for coordinating such tests with the <strong>Work Progress Schedule</strong> to avoid delay."], "related": [["progress-schedule", "Progress Schedule", "Progress Schedule"], ["work-program", "Work Program", "Work Program"], ["work-programme", "Work Programme", "Work Programme"], ["work-schedule", "Work Schedule", "Work Schedule"], ["work-plan", "Work Plan", "Work Plan"]], "related_snippets": [], "updated": "2025-07-10T04:27:38+00:00"}, "json": true, "cursor": ""}}