Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.
Constructive Termination means:
Constructive Termination Without Cause means the termination of the Executive’s employment at his initiative after, without the Executive’s prior written consent, one or more of the following events:
Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,
Allowed Delay has the meaning set forth in Section 2(c)(ii).
Catastrophic disability means a physical and not a psychological
Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:
Disability Date means the date on which a Participant is deemed disabled under the employee benefit plans of the Corporation applicable to the Participant.
Delivery Period Termination Date Has the meaning specified in the Related Pass Through Trust Supplement.
Pregnancy disability means a pregnancy-related medical condition or miscarriage.
Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to:
Effective Termination Date has the meaning set forth in Section 10(b) hereof.
Just Cause means:
Disability or Disabled means that during the Elimination Period and your Own Occupation Period you are, as a result of Physical Disease, Injury, Mental Disorder, Substance Abuse or Pregnancy, unable to perform one or more of the Material Duties of your Own Occupation, and, due to such inability, your Work Earnings are less than 80% of your Indexed Predisability Earnings, and you are incapable of earning 80% or more of your Indexed Predisability Earnings. Your Work Earnings may be Deductible Income. See the “LTD Benefit Calculation” and “Deductible Income” sections.
Termination due to Disability means a termination of the Executive’s employment by the Company because the Executive has been incapable, after reasonable accommodation, of substantially fulfilling the positions, duties, responsibilities and obligations set forth in this Agreement because of physical, mental or emotional incapacity resulting from injury, sickness or disease for a period of (A) six (6) consecutive months or (B) an aggregate of nine (9) months (whether or not consecutive) in any twelve (12) month period. Any question as to the existence, extent or potentiality of the Executive’s disability shall be determined by a qualified physician selected by the Company with the consent of the Executive, which consent shall not be unreasonably withheld. The Executive or the Executive’s legal representatives or any adult member of the Executive’s immediate family shall have the right to present to such physician such information and arguments as to the Executive’s disability as he, she or they deem appropriate, including the opinion of the Executive’s personal physician.
Due Cause means any of the following events:
Involuntary Termination Without Cause means Executive’s dismissal or discharge other than for Cause. The termination of Executive’s employment as a result of Executive’s death or disability will not be deemed to be an Involuntary Termination Without Cause.
Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.
Network Termination Point (NTP) means the physical point at which a subscriber is provided with access to a public communications network; in the case of networks involving switching or routing, the NTP is identified by means of a specific network address, which may be linked to a subscriber number or name;
Service-connected disability means a disability incurred or aggravated in the line of duty in the active military, naval, or air service as described in 38 USC 101(16).
Force Majeure Period has the meaning specified in Section 13.1.
Voluntary Termination for Good Reason means that the Executive voluntarily terminates his employment after any of the following are undertaken without Executive’s express written consent: