Examples of Time of Performance in a sentence
The delivery and acceptance of any Goods after the Time of Performance shall not be deemed a waiver of the right of the Agency Chief Contracting Officer to terminate this Contract or to require the delivery of any undelivered Goods in accordance with this Contract or any other remedy whether contractual or otherwise stated in law or in equity.
If the performance of the Seller is delayed by an act or omission of the City, the Seller shall be allowed a reasonable extension in the Time of Performance, and no claim for the delay or damages resulting therefrom shall be made by or allowed to the Seller.
A Job Description must be developed by the relevant function for all new positions prior to initiation of an SRF.
Time of Performance (i.e., hours of the day, days of the week, etc.).
The Consultant shall have no claim for damages, for compensation in excess of the amount contained in this Agreement or for a delay or extension of the Time of Performance as a result of any such removal or replacement.
The Consultant represents and certifies that the Services shall be performed in accordance with the standards of professional practice, care, and diligence practiced by recognized consulting firms in performing services of a similar nature in existence at the Time of Performance.
The Consultant shall have no claim for damages and shall not bill the City for additional time and materials charges as the result of any portion of the Services which must be duplicated or redone due to such termination or for any delay or extension of the Time of Performance as a result of any such termination, reassignment, or resignation.
The services or goods required of the CONTRACTOR under this Contract shall be performed and completed in accordance with the Time of Performance set forth in Attachment-S3, which is made a part of this Contract.
The Consultant shall have no claim for damages, for compensation in excess of the amount contained in this Agreement, or for a delay or extension of the Time of Performance as a result of any such removal or replacement.
The City may modify the Time of Performance at any time upon 15 days prior written notice to the Consultant.