Tenant Architect definition

Tenant Architect has the meaning given in Schedule 4.
Sample 1
Tenant Architect means the architect selected and employed ---------------- by Tenant (subject to Landlord's approval and the provisions of Paragraph 1(b) below) for the preparation of the Tenant Working Drawings (excluding the Tenant Engineering Drawings).
Sample 1
Tenant Architect means architect or engineer appointed by the Landlord to prepare the Tenant Plans and Specifications, as provided in the Work Letter.
Sample 1

Examples of Tenant Architect in a sentence

  • Notify Landlord, Tenant, Architect, and testing laboratory sufficiently in advance of expected time for operations requiring testing services.

  • Further, Landlord shall have the right to require Tenant, Architect and the Contractor to meet with Landlord to discuss the progress of the preparation of plans and specifications and the construction of the Improvements, as deemed reasonably necessary by Landlord.

  • The majority of courses are classified into Management, Law, Economics, and Construction aspects.

  • Music Glue empowers artists to sell tickets, music, merch and experiences direct to their fans from their online store.

  • A pre-construction meeting must be held with the Tenant, Architect, Engineer Consultant, General Contractor, (“Contractor”) and Landlord’s Agent.

  • Blend of 3 native Sicilian grapes – Grecanico, Inzolia, & Grillo.

  • Since I had no idea who those people were, I asked Marc Rolfes specifically to go to those individuals and issue that invitation.

  • On or before the date set forth in Schedule ---------------------- 1, Tenant, Architect and the Engineers shall complete the architectural and engineering drawings for the Premises, and the final architectural working drawings in a form which is complete to allow subcontractors to bid on the work, to obtain all applicable permits, and to subsequently construct the work (collectively, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's reasonable approval.

  • On behalf of Tenant, Architect shall prepare all plans and working drawings relating to the structural and architectural elements of the Tenant Improvements, and Engineer and other approved sub-consultants and professionally licensed subcontractors shall prepare all plans and engineering working drawings relating to mechanical, electrical, plumbing, HVAC, life safety, and interior sprinkler work with respect to the Tenant Improvements, to the extent such work is not part of the existing base building.

  • If Tenant contends that a Commencement Date Delay has occurred, Tenant shall notify Landlord in writing within two (2) business days of each of (i) the date upon which such Commencement Date Delay becomes lcnown to Tenant, Architect, or Contractor and (ii) the date upon which such Commencement Date Delay ends (the “Termination Date”).


More Definitions of Tenant Architect

Tenant Architect shall be as defined in Paragraph 6(a) of Exhibit A attached hereto and incorporated herein. -------------- ---------
Sample 1
Tenant Architect means an architect selected by Tenant and acceptable to Landlord that is licensed to practice architecture in Washington State.
Sample 1
Tenant Architect means O'Xxxxx Xxxx and Associates, which Tenant Architect is hereby approved by Landlord and shall be employed by Tenant (at Tenant's cost) for the preparation of the Tenant Working Drawings (excluding the Tenant Engineering Drawings).
Sample 1

Related to Tenant Architect

  • Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

  • Project Architect means the professional architect or engineer employed by the Owner as architect or engineer of record for the Project and its consultants.

  • Landscape architect means a person who holds a license to practice landscape architecture in the state of California Business and Professions Code, Section 5615.

  • Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.

  • Architect/Engineer or “A/E” means the Person identified in the Agreement responsible for providing professional design services and construction contract administration for the Project. The A/E shall be (1) a registered architect holding a license and certificate of authorization issued by the Ohio Architects Board pursuant to ORC Chapter 4703, (2) a landscape architect holding a license and certificate of authorization issued by the Ohio Landscape Architects Board pursuant to ORC Chapter 4703, or (3) a professional engineer or professional surveyor holding a license and certificate of authorization issued by the Ohio Engineers and Surveyors Board pursuant to ORC Chapter 4733. As used in the Agreement, the term A/E may include a criteria architect or engineer for a Design-Build project.

  • Architect/Engineer (A/E means a person registered as an architect pursuant to Tex. Occ. Code Ann., Ch. 1051, as a landscape architect pursuant to Tex. Occ. Code Ann., Ch. 1052, a person licensed as a professional engineer pursuant Tex. Occ. Code Ann., Ch. 1001, and/or a firm employed by Owner or Design-Build Contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • Tenant Improvements Defined in Exhibit B, if any.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Construction Consultant means the construction consultant, if any, engaged by Administrative Agent with respect to the Project.

  • Architects means any Architect whom the Vendors and the Builder have appointed as the Architects for the Project / Buildings time to time.

  • Building Contractor means the building contractor or developer appointed or to be appointed by the Grant Recipient in respect of a Firm Scheme; Business Day means any day other than a Saturday, Sunday or a statutory Bank Holiday in England;

  • Site Engineer means an Engineer appointed by the SBIIMS at site as their representative for day-to-day supervision of work and to give instructions to the contractors.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Construction Contractor means a person who undertakes to or offers to undertake to, or purports to have the capacity to undertake to, or submits a bid to, or does himself or by or through others, construct, alter, repair, add to, subtract from, improve, move, wreck, or demolish any building, highway, road, railroad, excavation, or other structure, project, development, or improvement to real property, or to do any part thereof. "Construction contractor" includes subcontractors, specialty contractors, prime contractors, and any person receiving consideration for the general supervision and/or coordination of such a construction project except for remediation contracting. This definition shall govern without regard to whether or not the construction contractor is acting in fulfillment of a contract.

  • Tenant means any Person leasing, subleasing or otherwise occupying any portion of the Property under a Lease or other occupancy agreement.

  • Landlord means the owner, lessor or sublessor of the dwelling unit or the building of which such

  • Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and

  • Architect/ consultants means and refer to the Consultants appointed by NU as Architect Consultants.

  • Building Project means the aggregate combined parcel of land on a portion of which are the improvements of which the Premises form a part, with all the improvements thereon, said improvements being a part of the block and lot for tax purposes which are applicable to the aforesaid land.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Electrical contractor means an electrical contractor as defined in the Regulations;

  • Residential contractor means a licensed contractor that holds an endorsement as a:

  • Work area means a room or defined space in a workplace where hazardous chemicals are produced or used, and where employees are present.

  • Design-Builder means the Person selected pursuant to the RFP that enters into the Contract with the Department to design and construct the Project (also referred to as the “Design-Build Team”).