Technical Acceptance Date definition

Technical Acceptance Date of the Aircraft means the date on which Technical Acceptance of the Aircraft occurs.
Sample 1Sample 2
Technical Acceptance Date means the date the Technical Acceptance Certificate is executed by Xxxxxx and Lessor;
Sample 1
Technical Acceptance Date means the date on which Buyer delivers the Technical Acceptance Certificate to Seller.
Sample 1

Examples of Technical Acceptance Date in a sentence

  • If the Employee has five (5) or more consecutive One-Year Breaks in Service, his service after such One-Year Breaks in Service shall not be counted as years of Vesting Service for the purpose of determining the Vested percentage of that portion of his Employer contributions allocated with respect to his service before such One-Year Breaks in Service and separately accounted for under Section 5.1.4.

  • Lessee shall pay to Seller the amount of US$ * (the “Lessee Contribution to Aircraft Condition”) within three (3) Business Days after the Technical Acceptance Date (but in any case prior to commencement of the Ferry Flight) which amount shall, together with the balance to be paid by the Purchaser, constitute a pro tanto portion of the Purchase Price.

  • Technical Acceptance Date of the Aircraft means the date on which Technical Acceptance of the Aircraft occurs.

  • Seller replied that Seller took measures to ensure that all material records and the aircraft were available for inspection prior to the Outside Technical Acceptance Date of January 31, and both parties had agreed the purchase price would be reduced by the cost necessary for the aircraft to be painted after closing.

Related to Technical Acceptance Date

  • Final Acceptance Date means the date on which Final Acceptance occurs.

  • Operational Acceptance Tests means the tests specified in the Technical Requirements and Agreed Project Plan to be carried out to ascertain whether the System, or a specified Sub system, is able to attain the functional and performance requirements specified in the Technical Requirements and Agreed Project Plan, in accordance with the provisions of GCC Clause 27.2 (Operational Acceptance Test).

  • Acceptance Date has the meaning set forth in Section 2.05(a)(v)(D)(2).

  • Final completion and acceptance means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.

  • Final Acceptance means final written acceptance of all the Work by the Commissioner, a copy of which shall be sent to the Contractor.

  • Acceptance Test is a test of the Features executed by the Customer to prepare the acceptance.

  • Contract Effective Date means the date agreed upon by the parties for beginning the period of performance under the contract. In no case shall the effective date precede the date on which the contracting officer or designated higher approval authority signs the document.

  • Final Completion Date means the date on which Final Completion occurs.

  • Operational Acceptance means the acceptance by the Procuring Entity of the Facilities (or any part of the Facilities where the Contract provides for acceptance of the Facilities in parts), which certifies the Contractor's fulfillment of the Contract in respect of Functional Guarantees of the Facilities (or the relevant part thereof) in accordance with the provisions of GCC Clause 28 (Functional Guarantees) hereof and shall include deemed acceptance in accordance with GCC Clause 25 (Commissioning and Operational Acceptance) hereof.

  • Acceptance Day shall have the meaning specified in paragraph 2B(5).

  • XXXX Acceptance Form means the “Acceptance Form for End User License Agreement (for SAP On Premise indirect sales)” which will be provided by SAP on a deal by deal basis.

  • Acceptance Tests means those tests performed during the Performance Period which are intended to determine compliance of Equipment and Software with the specifications and all other Attachments incorporated herein by reference and to determine the reliability of the Equipment.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Acceptance Testing mean the tests, reviews and other activities that are performed by or on behalf of Agency to determine whether the Deliverables meet the Acceptance Criteria or otherwise satisfy the Agency, as determined by the Agency in its sole discretion.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Shipment Date means the date for shipment of Product requested by Buyer in a Purchase Order.

  • Letter of Acceptance (LOA means the written notice issued by JMRC to the selected bidder(s) intimating the acceptance of selected bidder's Proposal for the award of Lease;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Interconnection Activation Date means the date that the construction of the joint facility Interconnection arrangement has been completed, trunk groups have been established, joint trunk testing is completed and trunks have been mutually accepted by the Parties.

  • Final Acceptance Certificate means the certificate that shall be issued by the Engineer to the Contractor upon the satisfactory completion of the contract by the Contractor.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Date of Acceptance means the date, which appears on the Notice of Acceptance and if no date appears is the date on which the Principal sent the Notice of Acceptance accepting the Contractor’s Tender.

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);

  • technical specification means a document that prescribes technical requirements to be fulfilled by a product, process or service;

  • Scheduled Commercial Operation Date shall have the meaning ascribed to it in Clause 5.4.1;