Successful Vendor means the organization or person with whom the order is placed or who is contracted to execute the work as detailed in the bid.
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Final Completion Date means the date on which Final Completion occurs.
Test on Completion means such tests as prescribed in the Contract to be performed by the Contractor before the work is Taken Over by TSECL.
Project Completion Date means the date on which the Completion Certificate is issued;
Successful Proposer means any Proposer selected by the University to receive an Award as a result of this RFP and to enter into a Contract to provide the University with the products or services sought by this RFP.
Successful Proponent means a Proponent who the City may award the agreement to, as a result of this RFP document.
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.
Project Milestone means the project milestone set forth in Schedule-J;
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Virtual Completion means the premise is in the opinion of the Employer fit for occupation.
Start-Up Costs means all fees, costs, and expenses incurred in connection with establishing the State Mitigation Trust and the Indian Tribe Mitigation Trust and setting them up for operation. Start-up costs shall not include the cost of premiums for insurance policies.
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Substantial Completion Date means the date on which Substantial Completion occurs.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Scheduled Completion Date shall be the date set forth in Clause 10.3;