Stage 3 Completion Date means a day mutually agreed by the Parties, but which shall be as soon as reasonably practicable after Stage 2 Completion Date;
Target Completion Date has the meaning given such term in Section 3.3(b).
Project Completion Date means the date on which the Completion Certificate is issued;
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
Final Completion Date means the date on which Final Completion occurs.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Substantial Completion Date means the date on which Substantial Completion occurs.
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Scheduled Completion Date shall be the date set forth in Clause 10.3;
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Framework Commencement Date means [insert date dd/mm/yyyy];
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date
Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);
Milestone Date means the date set against the relevant Milestone in the Implementation Plan;
Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;
Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.
Stage 1 means the area at Port Xxxxxxx which is the subject of this Agreement and of the ERMP and which is shown bordered in purple as “stage 1” on Department of Land Administration 4 Miscellaneous Plan No. 1743;
Completion Deadline means August 15, 2018, or such later date as may be agreed to in writing by the Parties;
Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.
COMPLETION TIME means the period by date specified in the acceptance of tender for handing over the erected equipment/plant which are found acceptable by the Engineer being of required standard and conforming to the specifications of the contract.
Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.
Phase 1 means the first implementation phase of this section, beginning June 1, 2018 and ending May 31, 2022.