Stage 1 EPC Agreement definition

Stage 1 EPC Agreement has the meaning specified in the preamble.
Sample 1Sample 2Sample 3
Stage 1 EPC Agreement means the engineering, procurement and construction agreement between Owner and Contractor dated December 6th, 2013 for the engineering, procurement, construction, commissioning, start-up and testing of Subproject 1 and Subproject 2, to be located at the Stage 1 Site.
Sample 1Sample 2Sample 3
Stage 1 EPC Agreement has the meaning set forth in Section 17.1H.
Sample 1

Examples of Stage 1 EPC Agreement in a sentence

  • Notwithstanding anything to the contrary in this Agreement, the work performed under the Stage 1 EPC Agreement is governed by the Stage 1 EPC Agreement, and the Work performed under this Agreement is governed by this Agreement.

  • Such extension shall meet the requirements of this Attachment O and shall not relieve Contractor of any of its responsibilities to meet the requirements of Attachment O under the Stage 1 EPC Agreement.

  • The full amount of Five Hundred Million U.S. Dollars (U.S.$ 500,000,000) may be satisfied under either the Stage 1 EPC Agreement, the Stage 2 EPC Agreement or this Agreement.

  • The full amount of Five Hundred Million U.S. Dollars (U.S.$500,000,000) may be satisfied under either the Stage 1 EPC Agreement or this Agreement.

  • Owner shall provide Contractor with reasonable prior notice of access to the Off-Site Rights of Way and Easements by (i) any of Owner’s other contractors or subcontractors seeking to perform work within such Off-Site Rights of Way and Easements (except with respect to Contractor’s work performed under the Stage 1 EPC Agreement), and (ii) any Landowner.

  • Owner shall provide Contractor with access to the Work after Substantial Completion sufficient to enable Contractor to complete all Punchlist items, so long as such access does not unreasonably interfere with operation of Subproject 3 after Substantial Completion or Subproject 1 or Subproject 2 after substantial completion of Subproject 1 or Subproject 2 (as applicable) under the Stage 1 EPC Agreement and subject to any reasonable security or safety requirements of Owner.

  • Notwithstanding anything to the contrary in this Agreement, the work performed under the Stage 1 EPC Agreement is governed by the Stage 1 EPC Agreement, the work performed under the Stage 2 EPC Agreement is governed by the Stage 2 EPC Agreement, the work performed under the Stage 4 EPC Agreement is governed by the Stage 4 EPC Agreement and the Work performed under this Agreement is governed by this Agreement.

  • Without limiting the foregoing, if there are common issues of fact or law in connection with any Disputes in an arbitration conducted under this Article 18 and any disputes in connection with any arbitration under the Stage 1 EPC Agreement, either Party may consolidate the two arbitrations to the extent necessary to avoid inconsistent determinations.

  • If damage occurs to Subproject 1 or Subproject 2 prior to substantial completion of such applicable Subproject 1 or Subproject 2, liability for such damage shall be governed by the Stage 1 EPC Agreement.

  • Owner shall provide Contractor with reasonable notice of any request for access to the Stage 2 Site by (i) any of Owner’s other contractors or subcontractors seeking to perform work at the Site (except with respect to Contractor’s work performed under the Stage 1 EPC Agreement) or (ii) any Landowner.


More Definitions of Stage 1 EPC Agreement

Stage 1 EPC Agreement means the Fixed Price Turnkey Agreement for the Engineering, Procurement and Construction of the Corpus Christi Stage 1 Liquefaction Facility by between Owner and EPC Contractor dated December 6, 2013.
Sample 1

Related to Stage 1 EPC Agreement

  • EPC Agreement shall have the meaning set forth in the preamble to this Agreement.

  • Stage 1 means the area at Port Xxxxxxx which is the subject of this Agreement and of the ERMP and which is shown bordered in purple as “stage 1” on Department of Land Administration 4 Miscellaneous Plan No. 1743;

  • Subproject Agreement means any of the agreements referred to in Section 3.07 of this Agreement; and

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Development Schedule shall have the meaning set forth in Section 1.1.

  • Redevelopment Agreement means an agreement between the

  • Phase 1 means the first implementation phase of this section, beginning June 1, 2018 and ending May 31, 2022.

  • Development Agreement has the meaning set forth in the Recitals.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • service delivery and budget implementation plan means a detailed plan approved by the executive mayor of a municipality in terms of section 53(l)(c)(ii) of the MFMA for implementing the municipality's delivery of municipal services and its annual budget, and which must indicate

  • O&M Agreement means the agreement(s), if any, between the Company and the O&M Contractor for the operation and maintenance of the Facility to be entered into between the Company and the O&M Contractor, as amended or superseded from time to time;

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Service Level Agreement (SLA means the Contractual Commitment that prevails between the Buyer and the Service Provider with regard to type of service to be provided, deliverables, desired performance level, reliability and responsiveness, monitoring process and service level reporting, response and issue resolution time-frame, repercussions / penalties / remedies for service provider not meeting its commitment. The SLA of a particular contract may carry the matrix regarding the delivery of the goods and/or services and the corresponding penalties or remedies and liquidated damages as applicable.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Development Agreements means all development, utility or similar agreements included in the Permitted Encumbrances.

  • Service Level Agreement or SLA means the processes, deliverables, key performance indicators and performance standards relating to the Services to be provided by the Service Provider;

  • Project Plan means the document to be developed by the Contractor and approved by Webel Technology Ltd., based on the requirements of the Contract and the Preliminary Project Plan included in the Contractor’s bid. For the sake of clarity, the Agreed and Finalized Project Plan” refers to the version of the Project Plan submitted by the contractor after receiving the letter of Award and the same approved by Webel Technology Ltd. The project plan may be changed/ modified during the course of the project. Should the Project Plan conflict with the provisions of the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Phase 2 means the second implementation phase of this section, beginning June 1, 2022 and continuing thereafter.

  • Additional SDU Study means a deliverability study that a Developer may elect to pursue as that term is defined in OATT Section 25 (OATT Attachment S). For purposes of Section 23.4.5 of this Attachment H, “Affiliated Entity” shall mean, with respect to a person or Entity:

  • Phase 2 Clinical Trial means a human clinical trial of a product in any country that would satisfy the requirements of 21 C.F.R. 312.21(b) and is intended to explore a variety of doses, dose response, and duration of effect, and to generate initial evidence of clinical safety and activity in a target patient population, or a similar clinical study prescribed by the relevant Regulatory Authorities in a country other than the United States.

  • SWS wage assessment agreement means the document in the form required by the Department of Education, Employment and Workplace Relations that records the employee’s productive capacity and agreed wage rate

  • Development Milestone Event has the meaning set forth in Section 7.1.

  • Development Plan has the meaning set forth in Section 3.2.

  • Collaboration Agreement has the meaning set forth in the Recitals.