Sectional Completion definition

Sectional Completion means completion of a Section per Clause 33.1;
Sample 1Sample 2Sample 3
Sectional Completion completion of a Section in accordance with the terms of the relevant Building Contract but excludes any landscaping works that it is not possible to complete because of the planting season in which practical completion occurs “Services Works” the installation and connection of:
Sample 1
Sectional Completion means Practical Completion of a Section as certified by the Construction Manager;
Sample 1

Examples of Sectional Completion in a sentence

  • Sectional Completion of Works If sectional completion is specified in the Special Conditions of Contract (SCC), references in the Conditions of Contract to the Works, the Completion Date, and the Intended Completion Date shall apply to any Section of the Works (other than references to the Completion Date and Intended Completion Date for the whole of the Works).

  • Sectional Completion of WorksIf sectional completion is specified in the Special Conditions of Contract (SCC), references in the Conditions of Contract to the Works, the Completion Date, and the Intended Completion Date shall apply to any Section of the Works (other than references to the Completion Date and Intended Completion Date for the whole of the Works).

  • IfNumber of GC ClauseAmendments of, and Supplements to, Clauses in the General Conditions of Contract Sectional Completion and Damages per Section have been agreed, the latter should be specified here]GCC 48.1The Bonus for the whole of the Works is [insert percentage of final Contract Price] per day.

  • If Sectional Completion and Damages per Section have been agreed, the latter should be specified here]GCC 48.1The Bonus for the whole of the Works is [insert percentage of final Contract Price] per day.

  • If Sectional Completion and Damages per Section have been agreed, the latter should be specified here] GCC 48.1 The Bonus for the whole of the Works is [insert percentage of final Contract Price] per day.

  • The maximum amount of liquidated damages for the whole of the Works is [insert percentage] of the final Contract Price.[Usually liquidated damages are set between 0.05 percent and 0.10 percent per day, and the total amount is not to exceed between 5 percent and 10 percent of the Contract Price .lf Sectional Completion and Damages perSection have been agreed, the latter should be specified here} GCC 48.1The Bonus for the whole of the Works is [insert percentage of final Contract Price} per day.

  • If Sectional Completion and Damages per Section have been agreed, the latter should be specified here] GCC 52.1 The Bonus for the whole of the Works is [insert percentage of final Contract Price] per day.

  • X5 Sectional Completion Optional Used if the project requires sectional completion X7 Delay damages Applies Applies other than in exceptional circumstances agreed with NHSEI.

  • If Sectional Completion and Damages per Section have been agreed, the latter should be specified here.

  • If Sectional Completion and Damages per Section have been agreed, the latterNumber of GC ClauseAmendments of, and Supplements to, Clauses in the General Conditions of Contract should be specified here]GCC 48.1The Bonus for the whole of the Works is [insert percentage of final Contract Price] per day.


More Definitions of Sectional Completion

Sectional Completion means practical completion (as certified by the relevant contract administrator in respect of a Building Contract) of a section of the Developer Works in accordance with the relevant Building Contract;
Sample 1

Related to Sectional Completion

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Final Completion Date means the date on which Final Completion occurs.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Improvement completion assurance means a surety bond, letter of credit,

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.

  • Completion of work means completion of the entire contracted work. Exhaustion of quantity of any particular item mentioned in the bid document shall not imply completion of work or any component thereof.

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Time for Completion means the time for completing the Works as stated in the Contract Data (or as extended under Sub-Clause 7.3), calculated from the Commencement Date.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.