Examples of Scheduled Mechanical Completion Date in a sentence
The relevant portions of Article 3.3 state:3.3.2 Contractor shall achieve Mechanical Completion no later than the Scheduled Mechanical Completion Date and Construction Completion no later than the Scheduled Construction Completion Date.
Therefore, the Parties have agreed to quantify and to agree upon such damages in advance.3.3.3 In the event Contractor fails to achieve (a) Mechanical Completion by the Scheduled Mechanical Completion Date or (b) Construction Completion by the Scheduled Construction Completion Date, in either case, Contractor agrees to pay Covanta as liquidated damages (and not as a penalty nor subject to any proof of such loss)Contract art.
Change Orders shall include the adjustment, if necessary, in the Preparation and Material Receipt Commencement Date, the Scheduled Mechanical Completion Date, Construction Commencement Date or the Guaranteed Maximum Price.
This program met the evidence-based or research-based requirement for an Option B sentence.
Willbros shall give written notice to Cheniere of any requests, claims or proposals for adjustments to the Work, the Guaranteed Maximum Price, the Preparation and Material Receipt Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date for Changes directed by Cheniere or for circumstances otherwise permitted by this Agreement within the time frame and in accordance with Paragraph 14.1.
The Work Plan shall represent Willbros’ best judgment as to how it shall achieve Mechanical Completion by the Scheduled Mechanical Completion Date, and shall be a detailed graphic representation of all significant aspects of the Work showing Willbros’ plans for performance of the Work.
Contractor shall respond promptly to any change requests for estimates of the effects, if any, which the proposed change will have on the Project Budget or a Lump Sum Separated Price Contract and the Scheduled Mechanical Completion Date.
Adjustments to the Guaranteed Maximum Price, the Preparation and Material Receipt Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date shall only be made by Change Order.
As reasonably requested by Cheniere, Willbros shall revise the Work Plan to include the effect of Change Orders and Amendments and to reflect actual Work in progress as agreed with Cheniere, provided, however, Willbros may not modify the Preparation and Material Receipt Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date without a Change Order being executed in accordance with this Agreement.
Nothing in this Paragraph 15 shall be construed to revise the Critical Milestone Dates or the Scheduled Mechanical Completion Date.