Revised Milestone Date definition

Revised Milestone Date any revised date which is set for the Achievement of a Milestone;
Sample 1Sample 2Sample 3
Revised Milestone Date means any revised date, which is set for the Achievement of a Milestone.
Sample 1

Examples of Revised Milestone Date in a sentence

  • The Authority shall: consider the duration of the Delay, the nature of the Authority Default and the effect of the Delay and the Authority Default on the Concessionaire's ability to comply with the Implementation Plan; consult with the Concessionaire Representative in determining the effect of the Delay and how to minimize such effect where reasonably practicable; fix a Revised Milestone Date; and if appropriate, make any consequential revision to subsequent Milestones in the Implementation Plan.

  • The Authority Representative shall: c.1. consider the duration of the Delay, the nature of the Authority Cause and the effect of the Delay and the Authority Cause on the Contractor's ability to comply with the Implementation Plan; c.2. consult with the Contractor Representative in determining the effect of the Delay; c.3. fix a Revised Milestone Date; and c.4. if appropriate, make any consequential revision to subsequent Milestones in the Delivery Plan.

Related to Revised Milestone Date

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Milestone 2 means achievement of annual Net Sales of at least $35,000,000 during any Calendar Year ending on or before December 31, 2024.

  • Development Milestone Event has the meaning set forth in Section 7.1.

  • Milestone Dates means the dates for completion of specified Project activities as contained in the Project Schedule.

  • Milestone Event has the meaning set forth in Section 8.4.

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Milestone 1 means achievement of annual Net Sales of at least $20,000,000 during the Calendar Year ending on December 31, 2021.

  • Performance Milestone means an act or event specified in section 5.1 and described in section 9 of the EPLA.

  • Development Milestone Payment shall have the meaning set forth in Section 9.2(a).

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Milestone Events has the meaning set forth in Section 3.3 (Milestone Payments).

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Milestone means an event or task described in the Implementation Plan which, if applicable, must be completed by the relevant Milestone Date;

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Milestone Payment Date has the meaning set forth in Section 2.4(a).

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Final Completion Date means the date on which Final Completion occurs.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Sales Milestone Payment is defined in Section 5.3.

  • Deadline Date has the meaning set forth in Section 4.1(f).

  • EBITDA Target means the Company's projected earnings before interest, taxes, one-time transition expenses, non-cash compensation expense charges, depreciation and amortization, as contained in the Company's budget for the Applicable Period and which is approved by the Board (without reference to any adjustments or revision, upwards or downwards, to such projected earnings which are subsequently approved by the Board as part of any subsequent revision to such budget), and (ii) the term "Financial Results" shall mean the Company's EBITDA calculated by reference to the Company's financial statements for the Applicable Period as filed with the Securities and Exchange Commission (the "SEC").

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Milestone Failure means a failure by the Grant Recipient fully to achieve any Milestone by the relevant Milestone Date;

  • Milestones means control points in the project that help to chart progress. Milestones may correspond to the completion of a key deliverable, allowing the next phase of the work to begin. They may also be needed at intermediary points so that, if problems have arisen, corrective measures can be taken. A milestone may be a critical decision point in the project where, for example, the consortium must decide which of several technologies to adopt for further development.

  • Final Approval Date means the date on which the Court enters its Order and Judgment approving the Settlement.