Required Decommissioning Completion Date means the date falling nine (9) months after the Execution Date.
Project Completion Date means the date on which the Completion Certificate is issued;
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Final Completion Date means the date on which Final Completion occurs.
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
Target Completion Date has the meaning given such term in Section 3.3(b).
Substantial Completion Date means the date on which Substantial Completion occurs.
Commissioning Date means that date when construction of the contemplated Project is complete, and the Maintenance Term commences;
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Commissioning Period means, with respect to each Subproject, the period commencing upon the first delivery of Feed Gas to the Subproject in accordance with Sections 4.8 and 11.1 of the Agreement continuing through achievement of RFSU, commissioning, Start Up, Performance Testing and achievement of Substantial Completion for such Subproject.
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Commissioning test means tests applied to the Generating Facility, after completion of the construction of the Generating Facility, in order to verify that the Generating Facility may be released for Operation.
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Decommissioning Plan means the document containing detailed information on the proposed decommissioning and covering the following: the selected decommissioning strategy; the schedule, type and sequence of decommissioning activities; the waste management strategy applied, including clearance; the proposed end state; the storage and disposal of the waste from decommissioning; the timeframe for decommissioning; the cost estimates for the completion of decommissioning; and the objectives, expected results, milestones, target dates, as well as the corresponding key performance indicators, including, as appropriate, earned value based indicators. The plan is prepared by the nuclear facility license holder and is reflected in the multiannual work programmes of the Programme;
Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);
Project Implementation Unit or “PIU” means the unit referred to in Section I.A.1(b) of Schedule 2 to this Agreement.
Generation Interconnection Feasibility Study means a study conducted by the Transmission Provider (in coordination with the affected Transmission Owner(s)) in accordance with Tariff, Part IV, section 36.2.
Commissioning Tests means all of the procedures and tests which, in accordance with the Reasonable and Prudent Standard, and in compliance with industry guidelines, practices and standards, are:
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Generation Interconnection Facilities Study means a Facilities Study related to a Generation Interconnection Request.
Construction Completion means physical construction of a cleanup action component is complete.
Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.
Scheduled Completion Date shall be the date set forth in Clause 10.3;
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;