Project Milestone Completion Certificate definition

Project Milestone Completion Certificate means the certificate issued to the Concessionaire by the Concessioning Authority as described in Article 2.8 and Article 2.8.1.
Sample 1Sample 2Sample 3
Project Milestone Completion Certificate upon written intimation to Con cessioning Authority of such completion. The Concessioning Authority on its part, after detailed inspections of the Project relating to the requirements set out in Schedules and in compliance with the Project Milestone set out in Article 2.8 and on verifyi ng the relevant documentation, shall promptly and in any case within 30 (Thirty) days from the date of request therefore, issue such Certificate.
Sample 1

Examples of Project Milestone Completion Certificate in a sentence

  • The Concessionaire shall complete the construction of the Project and its related services and facilities as per the Project Milestone defined under Article 2.8 and obtain Project Milestone Completion Certificate.

  • The Concessioning Authority on its part, after detailed inspections of the Project, perusal of the Report, verification of the relevant documentation and verification of certificates issued by the competent authorities, shall promptly and in any case within 30 (Thirty) days from the date of request , either issue the Project Milestone Completion Certificate or deny the issuance thereof giving reasons 2.9 Consideration to Concessioning Authority 2.9.1 Annual Concession Feea.

  • The Concessioning Authority on its part, after detailed inspections of the Project, perusal of the Report by the Project Engineer , verification of the relevant documentation and verification of certificates issued by the competent authorities, shall promptly and in any case within 30 (Thirty) days from the date of request , either issue the Project Milestone Completion Certificate or deny the issuance thereof giving reasons 2.9 Consideration to Concessioning Authority 2.9.1 Annual Concession Feea.

  • The Concessionaire shall be required to complete the operation, maintenance and construction of the Project and its related services and facilities as per the Project Milestone defined under Article 2.8 and obtain Project Milestone Completion Certificate.

  • The Concessionaire shall be required to complete the operation, maintenance and Development of the Project and its related services and facilities as per the Project Milestone defined under Article 2.8 andobtain Project Milestone Completion Certificate.

  • The Authority on its part, after detailed inspections of the Project, perusal of the Report of the Project Engineer , verification of the relevant documentation and verification of certificates issued by the competent authorities, shall promptly and in any case within 30 (Thirty) days from the date of request , either issue the Project Milestone Completion Certificate or deny the issuance thereof giving reasons 2.9 Consideration to Authority 2.9.1 Annual Concession Feea.

  • The Authority on its part, after detailed inspections of the Project, verification of the relevant documentation and verification of certificates issued by the competent authorities, shall promptly and in any case within30 (Thirty) days from the date of request , either issue the Project Milestone Completion Certificate or deny the issuance thereof giving reasons2.9 Consideration to Authority 2.9.1 Annual Concession Fee a.

Related to Project Milestone Completion Certificate

  • Final Completion Certificate has the meaning set forth in Section 11.6.

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Completion Certificate means the certificate to be issued by the Engineer-In- Charge when the work/s has been completed to his satisfaction as per terms of the contract.

  • Construction Completion Certificate means a document:

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Development Milestone Event has the meaning set forth in Section 7.1.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Milestone 2 means achievement of annual Net Sales of at least $35,000,000 during any Calendar Year ending on or before December 31, 2024.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion Date means the date on which Final Completion occurs.

  • Development Milestone Payment shall have the meaning set forth in Section 9.2(a).

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);

  • Project Deliverables means the Project deliverables set out in Schedule 2. Project Material means all the material including but not limited to documents, computer software, and data stored by any means which is created by the Fellow in the course of undertaking the Project.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.