Disbursement Schedule means the disbursement schedule as set out in an FAA;
Approved Project Budget means the most recent statement, approved by the FTA, of the costs of the Project, the maximum amount of Federal assistance for which the TJPA is currently eligible, the specific tasks (including specified contingencies) covered, and the estimated cost of each task.
Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.
Project Budget means the budget and project description included in the grant application. The Project Budget must succinctly describe all major elements of project work, the estimated cost of each, and clearly allocate requested grant funding and match contributions to each.
Project Costs means all allowable costs, as set forth in the applicable Federal cost principles, incurred by a recipient and the value of the contribu- tions made by third parties in accom- plishing the objectives of the award during the project period.
Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);
Project Completion Date means the date on which the Completion Certificate is issued;
Total Contract Price/Project Cost/TCO means the price payable to Service Provider over the entire period of Contract for the full and proper performance of its contractual obligations.
Construction Lender means a person who makes a construction loan.
Payment Date Advance Reimbursement has the meaning set forth in Section 8.03(a)(iii)(A) of the 20[•]-[•] Servicing Supplement.
Development Schedule shall have the meaning set forth in Section 1.1.
Total Contract Price/Project Cost/TCO means the price payable to Service Provider over the entire period of Contract for the full and proper performance of its contractual obligations.
Disbursement Request means a disbursement request from the Borrower to the Administrative Agent and the Collateral Agent in the form attached hereto as Exhibit C in connection with a disbursement request from the Unfunded Exposure Account in accordance with Section 2.04(d) or a disbursement request from the Principal Collection Subaccount in accordance with Section 2.18, as applicable.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Project Preparation Advance is modified to read “Preparation Advance” and its definition is modified to read as follows:
Original Project Cost means the capital expenditure incurred by the Generating Company or the Transmission Licensee, as the case may be, within the original scope of the project up to the cut-off date as admitted by the Commission;
Final completion and acceptance means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.
Commitment Schedule means the Schedule attached hereto identified as such.
Project Dollars means Defendants’ expenditures and payments incurred or made in carrying out the Environmental Mitigation Projects identified in Section VIII (Environmental Mitigation Projects) of this Consent Decree to the extent that such expenditures or payments both: (a) comply with the requirements set forth in Section VIII (Environmental Mitigation Projects) and Appendix A of this Consent Decree, and (b) constitute Defendants’ direct payments for such projects, or Defendants’ external costs for contractors, vendors, and equipment.
Advance Reimbursement Amount has the meaning stated in Section 4.4(b) of the Servicing Supplement.
Total Project Costs means the total amount of money required to complete the Project.
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
The Contract Price/Project Cost means the price payable to the Vendor under the Contract for the full and proper performance of its contractual obligations.
Final Disbursement Date means the last date on which Lender may make a Disbursement set forth in Section 10 of the Loan Authorization Agreement (including as amended by an Extension) or, if such date is not a Business Day, the next succeeding Business Day; provided, however, to the extent that Lender has not received cash collateral in the amount of the Letter of Credit Obligations or an equivalent full indemnity from Borrower or Guarantor, as applicable, with respect to Letter of Credit Obligations outstanding on the Final Disbursement Date, the Final Disbursement Date with respect to an advance to fund a drawing under such Letter of Credit shall be no later than thirty (30) days after any such drawing which may be no later than the expiry date of the Letter of Credit related thereto.
Minimum Disbursement Amount means Twenty-Five Thousand and No/100 Dollars ($25,000).
Wind-Down Budget means a budget to be prepared by the Debtors, and reasonably acceptable to the Deerfield Requisite Supporting Noteholders, the Unaffiliated Requisite Supporting Noteholders, and the Committee, which shall be filed with the Court as part of the Plan Supplement, and which may be amended from time to time after entry of the Confirmation Order, subject to the consent of the Oversight Committee, which consent shall not be unreasonably withheld, and which shall estimate the funds necessary to administer the Plan and wind down the Debtors’ affairs, including the costs of holding and liquidating the Estates’ remaining property, objecting to Claims, making the Distributions required by the Plan, prosecuting claims and Causes of Action that may be held by the Estates against third parties that are not released, waived or transferred pursuant to the Plan (including pursuant to Article X) or otherwise, paying Taxes, filing Tax returns, paying professionals’ fees and expenses, paying the fees and expenses of the Oversight Committee, funding payroll and other employee costs, providing for the purchase of errors and omissions insurance and/or other forms of indemnification for the Plan Administrator, and for all such items and other costs of administering the Plan, the Estates and the Liquidating Debtors (other than the Administrative and Priority Claims Reserve, the Disputed Claims Reserve, and the Professional Fee Reserve).