Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Project Completion Date means the date on which the Completion Certificate is issued;
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Construction Completion means physical construction of a cleanup action component is complete.
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Final Completion Date means the date on which Final Completion occurs.
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Phase 1 means the first implementation phase of this section, beginning June 1, 2018 and ending May 31, 2022.
Construction Completion Certificate means a document:
Improvement completion assurance means a surety bond, letter of credit,
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Substantial Completion Date means the date on which Substantial Completion occurs.
Target Completion Date has the meaning given such term in Section 3.3(b).
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Phase 2 means the second implementation phase of this section, beginning June 1, 2022 and continuing thereafter.
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Construction Work means any work in connection with
Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);
Final Completion Certificate has the meaning set forth in Section 11.6.
Commissioning test means tests applied to the Generating Facility, after completion of the construction of the Generating Facility, in order to verify that the Generating Facility may be released for Operation.
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.
Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.
Virtual Completion means the premise is in the opinion of the Employer fit for occupation.