Practical Completion of the Work definition

Practical Completion of the Work means when Contract Deficiencies identified during Performance Testing and previously identified but outstanding Contract Deficiencies have been corrected by the Contractor, or addressed and a course of action established by the Owner, and the state of the Work is so declared, in writing, by the Owner.
Sample 1Sample 2Sample 3
Practical Completion of the Work or “Practical Completion” means the date at which the Company determines that all work agreed in the quotation has been carried out.
Sample 1Sample 2

Examples of Practical Completion of the Work in a sentence

  • The Authorised Officer must not issue a Certificate of Practical Completion unless he/she is satisfied that Practical Completion of the Work has been reached.

  • Despite a slight drop in revenue, operating profit increased significantly as a result of the profit recognition for new projects commenced in last year and substantially developed in the period under review.

  • They do this by describing their goals, such as not supporting the negative impact of voluntourism, and developing local communities abroad.45 Some of them, such as Projects Abroad, even describe what a volunteering candidate should, in general, pay attention to when choosing a volunteering organisation.

  • Unless the Company agrees in writing to the contrary at pre-contract stage, 50% of the total value of any retention agreed will become payable to the Company immediately upon the Practical Completion of the Work.

  • If the Supplier supplies Work, or Goods and Work, after Practical Completion of the Work.

  • The Contractor must provide all statutory and necessary amenities and sanitary facilities for workmen and other persons lawfully upon the Site and remove them on Practical Completion of the Work.

  • There would also be the potential to impact the bowhead hunt in Barrow.

  • The time for Practical Completion of the Work shall be extended commensurate with any delay or delays in performance by either the Contractor or the Principal when such delay is caused by Force Majeure, and notice is given pursuant to Clause 50.2.

  • Total Completion of the WorkEdit text to suit project requirements.Unless a Performance Testing subphase of Facility Start-Up is specified in Section 01 91 01, edit this Section to delete all references to 'Performance Testing' and 'Practical Completion of the Work', ie:.1 Delete 1.1.2 to 1.1.2.3 inclusive..2 Delete reference to Practical Completion in 3.1..3 Delete reference to Performance Testing in 4.1.14..4 Delete articles 7., 8.

  • Insert number] days of the date specified in the notice for Practical Completion of the Work.

Related to Practical Completion of the Work

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Final Completion Date means the date on which Final Completion occurs.

  • Date of Practical Completion means the date certified in the QBCC Form 7 - Certificate of Practical Completion in accordance with Condition 28.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Construction Work means any work in connection with⎯

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Construction Phase Services means the coordination, implementation and execution of the Work required by this Agreement, which are further defined in Article 8.

  • The Work means each and every activity required for the successful performance of the services described in Section II, the Terms of Reference.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Tenant Improvements Defined in Exhibit B, if any.

  • Infrastructure improvement means permanent infrastructure that is essential for the public health and safety or that: